HomeMy WebLinkAboutPR 20127: PROFESSIONAL SERVICES FOR A PRELIMINARY DRAINAGE STUDY INTEROFFICE MEMORANDUM
Date: February 27, 2018
To: The Honorable Mayor and City Council
Through: Harvey Robinson, Interim City Manager
From: Armando Gutierrez, Jr., P.E., Director of Public Works
RE: P.R. 20127—Professional Services for a Preliminary Drainage Study
Introduction:
Approval of a professional services agreement with Arceneaux, Wilson and Cole, LLC of Port
Arthur, Texas for drainage studies in the Port Acres and Vista Village areas not to exceed a
combined amount of$66,655.00.
Background:
A drainage study performed in 1969 identified a drainage pipe system to be constructed along
67th Street from near West Port Arthur Road then westerly to discharge at the DD7 pump
station by the levee. This study will identify the contributing drainage basin and the
recommend pipe sizing based on new drainage design criteria. Areas affected will include
Garnet Avenue and surrounding areas.
There is a 30" inch drainage pipe on Maple Avenue that provides drainage for that section of
El Vista. The drainage begins at the end of Maple Avenue past Pine Avenue and flows towards
Roosevelt Avenue. However it turns south flows through the Tank farm area and behind the
residential area towards the El Vista Drainage Ditch.
In the recent storm events that line has proven to be undersize. This drainage study will
identify improvement needed to adequately provide drainage for future storm events.
Budget Impact:
Funding available by way of budget transfer from savings in personnel to the Professional
Services Account No. 001-1204-531.54-00.
Recommendation:
Recommend approval of the professional service agreement with Arceneaux, Wilson and Cole,
LLC for a fee not to exceed $66,655.00.
P.R. 20127
02/19/18 rtb
RESOLUTION NO.
A RESOLUTION AUTHORIZING THE INTERIM CITY MANAGER TO
EXECUTE CONTRACTS FOR PROFESSIONAL SERVICES BETWEEN
THE CITY OF PORT ARTHUR AND ARCENEAUX, WILSON AND
COLE, LLC FOR DRAINAGE STUDIES OF THE PORT ACRES AND
VISTA VILLAGE AREAS FOR A NOT-TO-EXCEED COMBINED
AMOUNT OF $66,655.00. FUNDING IS AVAILABLE IN PUBLIC
WORKS — DRAINAGE, PROFESSIONAL SERVICES ACCOUNT NO.
001-1204-531.54-00.
WHEREAS, drainage concerns exist due to flooding issues during heavy rainfall
events in the Port Acres and Vista Village areas; and,
WHEREAS, a drainage study is warranted to evaluate the drainage concerns in
the Port Acres and Vista Village areas; and,
WHEREAS, the Public Works Department has requested preliminary drainage
studies of the Port Acres and the Vista Village areas; and,
WHEREAS, Arceneaux, Wilson and Cole, LLC has submitted respective proposals
to perform a preliminary engineering drainage studies for the Port Acres area in the
amount of $43,680.00 and the Vista Village area in the amount of $22,975.00 for a
combined cost of $66,655.00; now therefore,
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF PORT
ARTHUR:
THAT, the facts and opinions in the preamble are true and correct; and,
THAT, the Interim City Manager is hereby authorized to execute a professional
services contract with Arceneaux, Wilson and Cole, LLC of Port Arthur, Texas (attached
as Exhibit "A" and "B") for the respective preliminary engineering drainage studies of
P.R. 20127
Page 2
Port Acres and Vista Village areas for engineering services in a not-to-exceed combined
amount of $66,655.00, funding available by way of budget transfer from savings in
personnel to the Professional Services Account No. 001-1204-531.54-00; and,
THAT, a copy of the caption of this Resolution be spread upon the Minutes of
the City Council.
READ, ADOPTED AND APPROVED this the day of , A.D. 2018 at a
meeting of the City of Port Arthur, Texas by the following vote:
Ayes: Mayor:
Councilmembers:
Noes:
Mayor
Attest:
Sherri Bellard
City Secretary
APPROVED A TO FORM: APPROVED FOR ADMINISTRATION:
I
Valecia Tizeno 1 W Harvey Robinson
City Attorney Interim City Manager
APPROVED AS FOR AVAILABLITIY OF /
FUNDS: £rmando G. ierrez, Jr., P.E.
Public Works Director/Ci ngi.-er
41,1"_
(4 I , I,
Andrew Vasque , CPA Clifton Williams, CPPB
Director of Finance Purchasing Manager
Exhibits Are Available For Review In The
City Secretary Office Or Online
EXHIBIT A
Exhibit A
Total of 18 pages
THE STATE OF TEXAS §
§
COUNTY OF JEFFERSON §
CONTRACT
FOR PROFESSIONAL SERVICES
(NON-FEDERAL FORM)
PART I - AGREEMENT
THIS AGREEMENT, entered into as of this day of , 2018 by and
between the City of Port Arthur,Port Arthur,Texas(hereinafter called the"CITY")acting herein by
its City Manager,hereunto duly authorized and Arceneaux Wilson&Cole LLC(hereinafter called
the"ENGINEER")acting herein by Joe M.Wilson,Jr.,PE,its President, hereunto duly authorized:
WITNESSETH THAT:
WHEREAS, the CITY desires to engage the Engineer to (1) render certain technical and
professional services hereafter described in"Scope of Services"or(2)perform certain work hereafter
described in "Scope of Services": NOW, THEREFORE, the Parties hereto do mutually agree as
follows:
1. EMPLOYMENT OF ENGINEER
The CITY hereby agrees to engage the ENGINEER and the ENGINEER hereby agrees to
perform the "Scope of Services"hereinafter set forth. This contract shall be performed in
Jefferson County,Texas.
2. SCOPE OF SERVICES
A. BASIC SERVICES
Engineering services in connection with the following described project, to wit:
Drainage Study for
Vista Village
AWC Project No. CPA-950
ENGINEER'S compensation for Basic Services shall be as set forth in Paragraph 5.
Page 1
The services rendered by ENGINEER for the Project to be designed for construction are divided into
three(3)distinct and sequential phases as follows:
I. Preliminary Phase—Preliminary studies, layouts, and cost estimates
. . I I -
. • .
Certain elements of the engineering work are covered under the Basic Services; others are
performed as Additional Services. Those elements of the engineering work which cannot be
accurately predetermined or controlled entirely by the ENGINEER are performed as
Additional Services.
These phases are expanded in the following outline:
A. BASIC SERVICES
1. PRELIMINARY PHASE
(a) Provide Project Management services to direct,supervise and coordinate the
various items of work within this Phase, including review of activities of
subcontracted engineers.
(b) Attend preliminary conference with the CITY and other interested parties
regarding the project in order to further define the work.
(c) Establish the scope of any soil and foundation investigations or any special
surveys and tests which, in the opinion of the ENGINEER,may be required,
and arrange for such work to be done, for the CITY'S account.
(d) Prepare layouts, cost estimates, studies and documentation as described in
attached Proposal shown in Exhibit 1.
2. DESIGN PHASE
. - --
subcontracted
required for design, and arrange for such work to be done, for the CITY'S
ascot:
advances),
Page 2
I. _ .
CITY.
-- a - -
3. CONSTRUCTION PHASE
subcontracted-engineers:
(b) Assist the CITY in the advertisements of the project for bids.
.
(e) Provide routine horizontal and vertical controls for use Contractor to do
(f) a.) Continuous services of a Resident Project Representative as intervals
- - - - ' -
Dom
- • - - - • - - - • - - ' - - - • - ., . _ -
Engineer.
(g) Arrange for construction testing as required by the Project, for the CITY'S
account.
(h) Consult with and advise NA.ith the CITY, issuc all instructions to tho
Page 3
Contractor requested by the CITY, and prepare and issue routine change
orders with CITY'S approval.
On matters requiring the CITY's involvement the ENGINEER shall provide
the CITY'S designated representative with all facts germane to such matters
decision of the CITY, the ENGINEER shall be notified of the CITY'S
• - -
Contractor is to review and stamp his approval on submittals prior to
-
(k) Conduct, in company with the CITY, a final inspection of the Project for
concerning Project status, as it may affect CITY'S final payment to the
Contractor.
ENGINEER'S compensation for Basic Services shall be as set forth in Paragraph 5.
Page 4
B. ADDITIONAL SERVICES
All work performed by ENGINEER at request of CITY which is not included in the
Basic Services defined above, shall constitute Additional Services. Unless included in said
Basic Services, Additional Services may include but are not limited to the following:
(1) Studies,tests,and process determination to establish basis of design for water
and waste treatment facilities.
(2) Land surveys and establishment of boundaries and monuments, and related
office computation and drafting.
(3) Preparation of property or easement descriptions.
(4) Preparation of any special reports required for marketing of bonds.
(5) Small design assignments(estimated construction cost less than
$100,000).
(6) Appearances before regulatory agencies.
(7) Assistance to the CITY as an expert witness in any litigation with third
parties, arising from the development or construction of the Project,
including preparation of engineering data and reports.
(8) Special investigations involving detailed consideration of operation,
maintenance and overhead expenses; preparation of rate schedules;
earnings and expense statements; special feasibility studies; appraisals;
evaluations; and material audits or inventories required for certification of
force account construction performed by the CITY.
(9) Special soil and foundation investigations, including field and laboratory
tests, borings, related engineering analyses, and recommendations.
(10) Detailed mill, shop and/or laboratory inspection of materials or equipment.
(11) Travel and subsistence required of the ENGINEER and authorized by the
CITY to points other than CITY'S or ENGINEER'S offices and Project
site.
(12) Additional copies of reports over ten (10) sets and additional sets of
Contract Document over twenty(20) sets.
(13) Preparation of applications and supporting documents for government
grants or planning advances for public works projects.
(14) Preparation of environmental statements and assistance to CITY in
preparing for and attending public hearings.
(15) Plotting, computing, and filing plats of subdivisions; staking of lots; and
related land planning and partitioning functions.
(16) Revision of contract drawings after a definite plan has been approved by
the CITY, redrawing of plans to show work as actually constructed.
(17) Services after issuance of Certificate of Completion.
(18) Services to investigate existing conditions or facilities or to make
measured drawings thereof, or to verify accuracy of drawings or other
information furnished by Client.
(19) Preparation of operating instructions and manuals for facilities and
training of personnel and assistance in operation of facilities.
Page 5
(21) Additional or extended services during construction made necessary by
work damaged by fire or other cause during construction, defective or
neglected work of contractor; services rendered after prolongation of
scheduled construction contract time by more than 5%, acceleration of
work schedule involving services beyond normal working hours; or default
under construction contract due to delinquency or insolvency.
(22) Providing any other service not otherwise included in this Agreement or
not customarily furnished in accordance with generally accepted
engineering practice.
(23) Any other special or miscellaneous assignments specifically authorized by
CITY.
ENGINEER'S compensation for Additional Services shall be as set forth in Paragraph 5.
3. TIME OF PERFORMANCE
ENGINEER will proceed immediately upon execution of this Contract with performance of
the services called for under the Basic Services with completion within 120 days after execution,
unless delayed by causes outside the control of ENGINEER,and will proceed with subsequent work
only on authorization by CITY. ENGINEER shall immediately submit to CITY in writing evidence
of delay satisfactory to the CITY Engineer's reasonable discretion,upon which an extension of time
equal to the period of actual delay shall be granted in writing.
4. INFORMATION AND SERVICES TO BE FURNISHED ENGINEER
It is agreed that the CITY will furnish, without charge, for the use of the Contract
information,data,reports,records,and maps as are existing,available,and necessary for the carrying
out of the work of the ENGINEER as outlined under "Scope of Services." The CITY and its
agencies will cooperate with the ENGINEER in every way possible to facilitate the performance of
the work described in this Contract.
5. COMPENSATION AND METHOD OF PAYMENT
A. COMPENSATION
CITY will pay ENGINEER for work performed and services rendered under
Paragraph 2"Scope of Services",(Basic Services and Additional Services)at the following
rates. It is agreed that total fees for Basic Services (including subcontracted engineering
services as described herein) under this Contract, as defined in Paragraph 2A and based on
the preceding schedule, shall be Twenty-Two Thousand Nine Hundred Seventy-Five
Dollars ($22,975.00). and shall be paid in increments based on monthly invoices.
Additional Services authorized in writing by the CITY will be compensated based upon
hourly rates established by the ENGINEER as shown in Attachment 2.
Page 6
B. PAYMENT
ENGINEER will invoice CITY Monthly for its services and charges incurred by
ENGINEER for subcontracted engineering services performed under the direction and
control of ENGINEER as described herein.
CITY agrees to pay ENGINEER at his office the full amount of each such invoice
upon receipt or as otherwise specified in this Agreement.A charge of one percent per month
shall be added to the unpaid balance of invoices not paid within 31 days after date of invoice.
The engineer shall pay any subcontractors no later than the tenth day after he receives
payment as required under Chapter 2251 Government Code of the Revised Civil Statutes of
Texas.
6. RECORDS
ENGINEER shall keep accurate records, including time sheets and travel vouchers, of all
time and expenses allocated to performance of Contract work. Such records shall be kept in the
office of the ENGINEER for a period of not less than five(5)years and shall be made available to
the CITY for inspection and copying upon reasonable request.
7. OWNERSHIP OF DOCUMENTS
All documents, including original drawings,estimates,specifications,field notes and data are
property of CITY. ENGINEER may retain reproducible copies of drawings and other documents.
All documents, including drawings and specifications prepared by ENGINEER are
instruments of service in respect to the project. They are not intended or represented to be suitable
for reuse by CITY or others on extensions of the Project or on any other project. Any reuse without
written verification or adaption by ENGINEER for the specific purpose intended will be at CITY'S
sole risk and without liability or legal exposure to ENGINEER and CITY shall indemnify and hold
harmless ENGINEER from all claims, damages, losses and expenses including attorneys' fees
arising out of or resulting therefrom. Any such verification or adaption will entitle ENGINEER to
further compensation at rates to be agreed upon by CITY and ENGINEER.
8. INSURANCE
All insurance must be written by an insurer licensed to conduct business in the State of Texas,
unless otherwise permitted by Owner. The ENGINEER shall, at his own expense, purchase,
maintain and keep in force insurance that will protect against injury and/or damages which may arise
out of or result from operations under this contract,whether the operations be by himself or by any
subcontractor or by anyone directly or indirectly employed by any of them,or by anyone for whose
acts any of them may be liable,of the following types and limits(no insurance policy or certificate of
insurance required below shall contain any aggregate policy year limit unless a specific dollar
amount(or specific formula for determining a specific dollar amount)aggregate policy year limit is
expressly provided in the specification below which covers the particular insurance policy or
certificate of insurance).
Page 7
1. Standard Worker's Compensation Insurance(with Waiver of Subrogation in favor of
the CITY of Port Arthur, its officers, agents and employees.)
2. Commercial General Liability occurrence type insurance. (No "XCU" restrictions
shall be applicable.) Products/completed operations coverage must be included,and
the CITY of Port Arthur, its officers, agents and employees must be named as an
additional Insured.
a. Bodily injury $500,000 single limit per occurrence or $500,000 each
person/$500,000 per occurrence.
b. Property Damage$100,000 per occurrence.
c. Minimum aggregate policy year limit$1,000,000.
3. Commercial Automobile Liability Insurance(including owned,non-owned and hired
vehicles coverage).
a. Minimum combined single limit of$500,000 per occurrence for bodily injury
and property damage.
b. If individual limits are provided minimum limits are $300,000 per person,
$500,000 per occurrence for bodily injury and $100,000 per occurrence for
property damage.
4. Contractual Liability Insurance covering the indemnity provision of this contract in
the same amount and coverage as provided for Commercial General Liability Policy,
specifically referring to this Contract by date,job number and location.
5. ENGINEER also agrees to maintain Professional Liability Insurance coverage"of
$250,000 minimum per occurrence/claim/policy year aggregate limits against
ENGINEER for damages arising in the course of, or as a result of, work performed
under this Contract. Coverage shall continue for a minimum of two(2)years after the
ENGINEER'S assignment under this Contract is completed.Additional Professional
Liability Insurance required is $0
ENGINEER shall cause ENGINEER'S insurance company or insurance agent to fill in all
information required (including names of insurance agencies, ENGINEER and insurance
companies, and policy numbers,effective dates and expiration dates)and to date and sign and do
all other things necessary to complete and make into a valid certificate of insurance the
CERTIFICATE OF INSURANCE Form attached to and made a part of this Contract, and
pertaining to the above listed Items 1,2,3,4, and 5; and before commencing any of the work and
within the time otherwise specified, ENGINEER shall file said completed Form with the CITY.
None of the provisions in said Form shall be altered or modified in any respect except as herein
expressly authorized. Said CERTIFICATE OF INSURANCE Form contains a provision that
coverages afforded under the policies will not be altered, modified or cancelled unless at least
fifteen(15)days prior written notice has been given to the CITY. ENGINEER shall also file with
the CITY valid CERTIFICATE(s)OF INSURANCE on like form from or for all Subcontractors
and showing the Subcontractor(s) as the Insured. Said completed CERTIFICATE OF
INSURANCE Form(s) shall in any event be filed with CITY not more than ten (10) days after
Page 8
execution of this Contract.
- , - • - - .. -
9. PROFESSIONAL LIABILITY
A. ENGINEER shall be responsible for the use and employment of reasonable skill and
care befitting the profession in the designs,drawings,plans,specifications,data,reports and
designation of materials and equipment provided by ENGINEER for the Project covered by
this Contract. Approval by CITY shall not constitute nor be deemed a release or waiver of
the responsibility and liability of ENGINEER for the accuracy and competency of such
designs, drawings, plans, specifications, data, reports and designation of materials and
equipment. Contractor will be responsible for the actual supervision of Construction
operations and safety measures involving the work, his employees and the public, but the
ENGINEER will advise the Contractor of any items requiring the attention and action of the
Contractor.
B. If services include periodic visits to the site to inspect work performed by another
Contractor,ENGINEER is responsible for exercising reasonable care and skills befitting the
profession to assure that the Contractor performs the work in accordance with Contract
Documents and to safeguard the CITY against defects and deficiencies in the work;provided,
however, ENGINEER does not guarantee or insure the work completed by the Contractor.
During visits to the construction site, and on the basis of the ENGINEER'S on-site
observations as an experienced and qualified design professional, he will keep the CITY
informed on the extent of the progress of the work, and advise the CITY of material and
substantial defects and deficiencies in the work of material and substantial defects and
deficiencies in the work of Contractors which are discovered by the ENGINEER or otherwise
brought to the ENGINEER'S attention in the course of construction, and may,on behalf of
the CITY exercise whatever rights the CITY may have to disapproved work and materials as
failing to conform to the Contract Documents.
C. In connection with the services of Resident Project Representatives,ENGINEER will
use the usual degree of care and prudent judgement in the selection of competent Project
Representatives, and the ENGINEER will use its best efforts to see that the Project
Representatives are on the job to perform their required duties. In performing these duties
and services (described in this sub-paragraph), ENGINEER is responsible for exercising
reasonable care and skill befitting the profession the assure that the Contractor performs the
work in accordance with Contract Documents and to safeguard the CITY against defects and
deficiencies in the work; provided, however, ENGINEER does not guarantee or insure the
work completed by the Contractor.
D. In performing these services the ENGINEER will at all times endeavor to protect the
CITY on the Project and work sites and safeguard the CITY against defects and deficiencies
Page 9
in the work of the Contractor; provided,however,ENGINEER does not guarantee or insure
the work completed by the Contractor, nor is ENGINEER responsible for the actual
supervision of construction operations or for the safety measures that the Contractor takes or
should take.
E. ENGINEER shall not be responsible for any excess of construction costs over an
amount estimated.
10. INDEMNIFICATION
ENGINEER shall comply with the requirements of all applicable laws,rules,and regulations
in connection with the services of ENGINEER and shall exonerate,indemnify and hold harmless the
CITY, its officers,agents and all employees from any and all liability, loss or damage arising out of
noncompliance with such laws,rules and regulations;without limitation,ENGINEER shall assume
full responsibility for payments of Federal, State and Local taxes or contributions imposed or
required under the Social Security,Worker's Compensation, and Income Tax Laws with respect to
ENGINEER'S employees. Further, ENGINEER shall exonerate, indemnify and hold harmless the
CITY, its officers, agents and all employees from any and all liability, loss, damages, expenses or
claims arising out of negligence of ENGINEER, its officers, agents and employees in connection
with any of the work performed or to be performed under this Contract by ENGINEER or as a result
of ENGINEER'S failure to use and employ reasonable skill and care befitting the profession in
accordance with paragraph 9 hereof. Further, ENGINEER shall exonerate, indemnify and hold
harmless the CITY, its officers,agents,and all employees from any and all liability, loss,damages,
expenses or claims for infringement of any copyright or patents arising out of the use of any plans,
design, drawings, or specifications furnished by ENGINEER in the performance of this Contract.
The foregoing indemnification provision shall apply to ENGINEER regardless ofwhether or not said
liability, loss, damages, expenses, or claims is caused in part by a party indemnified hereunder.
11. ADDRESS OF NOTICE AND COMMUNICATIONS
CITY: ENGINEER:
Harvey Robinson Arceneaux Wilson&Cole LLC
Interim City Manager 2901 Turtle Creek Dr., Suite 320
City of Port Arthur Port Arthur, Texas 77642
PO Box 1089 ATTN: Joe M. Wilson, Jr., PE
Port Arthur, Texas 77641-1089
All notices and communications under this Contract shall be mailed or delivered to CITY and
ENGINEER at the above addresses.
Page 10
12. CAPTIONS
Each paragraph of this Contract has been supplied with a caption to serve only as a guide to
the contents. The caption does not control the meaning of any Paragraph or in any way determine its
interpretation or application.
13. SUCCESSORS AND ASSIGNMENTS
The CITY and the ENGINEER each binds himself and his successors, executors,
administrators, and assigns to the other party of this Contract and to the successors, executors,
administrators and assigns of such other party,in respect to all covenants of this Contract. Except as
above, neither the CITY nor the ENGINEER shall assign, sublet, or transfer his interest in this
Contract without the written consent of the other. Nothing herein shall be construed as creating any
personal liability on the part of any officer or agent of any public body which may be a party hereto.
14. TERMINATION OF CONTRACT FOR CAUSE
If, through any cause, the ENGINEER shall fail to fulfill in timely and proper manner his
obligations under this Contract,or if the ENGINEER shall violate any of the covenants,agreements,
or stipulations of this Contract,the CITY shall thereupon have the right to terminate this Contract by
giving written notice to the ENGINEER of such termination and specifying the effective date
thereof,at least five(5)days before the effective date of such termination. In such event,all finished
or unfinished documents, data, studies, survey, drawings,maps, models, photographs, and reports
prepared by the ENGINEER under this Contract shall,at the option of the CITY,become its property
and the ENGINEER shall be entitled to receive just and equitable compensation for any work
satisfactorily completed hereunder.
Notwithstanding the above,the ENGINEER shall not be relieved of liability to the CITY for
damages sustained by the CITY by virtue of any breach of the Contract by the ENGINEER and the
CITY may withhold any payment to the ENGINEER for the purpose of setoff until such time as the
exact amount of damages due the CITY from the ENGINEER is determined.
15. TERMINATION FOR CONVENIENCE OF THE CITY
The CITY may terminate this Contract at any time by giving at least thirty(30)days notice in
writing to the ENGINEER. If the Contract is terminated by the CITY as provided herein, the
ENGINEER will be paid for the time provided and expenses incurred up to the termination date. If
this Contract is terminated due to the fault of the ENGINEER, Paragraph 14 hereof relative to
termination shall apply.
16. CHANGES
The CITY may, from time to time, request changes in the scope of the services of the
ENGINEER to be performed hereunder. Such changes, including any increase or decrease in the
amount of the ENGINEER'S compensation, which are mutually agreed upon by and between the
Page 11
CITY and ENGINEER shall be incorporated in written amendments to this Contract.
17. PERSONNEL
A. The ENGINEER represents that he has, or will secure at his own expense, all
personnel required in performing the services under this Contract. Such personnel
shall not be employees of or have any contractual relationship with the CITY.
B. All of the services required hereunder shall be performed by the ENGINEER or
under his supervision and all personnel engaged in the work shall be fully qualified
and, if applicable shall be authorized or permitted under State and local law to
perform such services.
C. None of the work or services covered by this Contract shall be subcontracted without
the prior written approval of the CITY. Any work or services subcontracted
hereunder shall be specified by written Contract or agreement and shall be subject to
each provision of this Contract.
18. REPORTS AND INFORMATION
The ENGINEER at such times and in such forms as the CITY may require,shall furnish the
CITY such periodic reports s it may request pertaining to the work or services undertaken pursuant to
this Contract,the costs and obligations incurred or to be incurred in connection therewith,and any
other matters covered by this Contract.
19. CIVIL RIGHTS
Under Chapter 106 Civil Practice and Remedies Code ofthe Revised Civil Statutes of Texas,
no person shall, on the grounds of race, religion, color, sex or national origin, be excluded due to
discrimination under any program or activity of the CITY.
The ENGINEER will carry out its work under this Contract in a manner which will permit
full compliance by the CITY with the Statute.
20. INTEREST OF ENGINEER AND EMPLOYEES
The ENGINEER covenants that he presently has no interest and shall not acquire any interest,
direct or indirect, in the study area or any parcels therein or any other interests which would conflict
in any manner or degree with the performance of his services hereunder.
The ENGINEER further covenants that in the performance ofthis Contract,no person having
any such interest shall be employed.
Page 12
21. INCORPORATION OF PROVISIONS REQUIRED BY LAW
Each provision and clause required by law to be inserted into the Contract shall be deemed to
be enacted herein and the Contract shall be read and enforced as though each were included herein.
If through mistake or otherwise any such provision is not inserted or is not correctly inserted, the
Contract shall be amended to make such insertion on application by either party.
EXECUTED IN TWO (2) counterparts (each of which is an original) on behalf of
ENGINEER by Joe M.Wilson,Jr.,PE, its President shown below,and on behalf of the CITY by its
City Manager.
ACCEPTED: PROPOSED AND AGREED TO:
CITY: ENGINEER:
Harvey Robinson Joe M. Wilson, Jr., PE
Interim City Manager Arceneaux Wilson & Cole LLC
DATE: DATE:
ATTEST ATTEST:
CITY Secretary
APPROVED AS TO FORM:
CITY Attorney
DATE:
Page 13
ATTACHMENT 1
SCHEDULE OF BILLABLE RATES
FOR PROFESSIONAL SERVICES
ICLASSIFICATION RATE
ENGINEERING SERVICES
• Principal Engineer $225.00 per hour
• Engineering Project Manager $200.00 per hour
• Staff Engineer $160.00 per hour
• Graduate Engineer, EIT $130.00 per hour
• Engineering Intern $ 30.00 per hour
SURVEYING SERVICES
• Registered Professional Land Surveyor $145.00 per hour
• 2-Man Crew $165.00 per hour
• 3-Man Crew $216.00 per hour
• Survey Coordinator $100.00 per hour
TECHNICAL SERVICES
• Engineering Technician III $100.00 per hour
• Engineering Technician II $ 82.00 per hour
• Engineering Technician I $ 68.00 per hour
• Resident Field Representative $ 80.00 per hour
SECRETARIAL/ADMINISTRATIVE SERVICES $ 60.00 per hour
IT SUPPORT $ 90.00 per hour
NON-LABOR EXPENSES
• Vehicle Travel IRS standard rate
• Computer Plotting, Reproductions At Cost
• Subcontracted Services Cost+ 10%
• Materials Cost+ 10%
• GPS Base Station w/One(1) Rover $250.00 per day
2018
Page 14
ATTACHMENT 2
VOL
" ARCENEAUX WILSON&COLE
February 19, 2018
Mr.Armando Gutierrez,PE
Director of Public Works
City of Port Arthur
PO Box 1089
Port Arthur,Texas 77641-1089
RE: Proposal for Preliminary Engineering Drainage Study
For Vista Village, Port Arthur,Texas
Dear Mr.Gutierrez:
Thank you for contacting us to review the drainage concerns in the Vista Village
Subdivision. Based on our field visit we will be focusing our drainage study in the
area bound by Pine Avenue,Maple Avenue to the west and south and 60=h Street
and Roosevelt Avenue to the north and east. The study will go beyond a
"desktop"study of available records,to include limited field data collection and
inventory of systems serving the vicinity. Fort this project,we propose the
following Scope of Services:
SCOPE OF SERVICES
1. Research and assemble available records relating to drainage from the
City,Jefferson County Drainage District 7,TxDOT and the US Army Corps
of Engineers.
2. Determine or verify contributing drainage area to subject area using maps
and field confirmation.
3. Perform surveyed cross sections along roads within the drainage area and
inventory driveway culverts.
4. Plot a contour and drainage area map of the subject area showing limited
topography.
409.724.711811
2901 Turtle Creek Dr.Scarce 320
Port Arthur Tf 77642 Engineering Surveying
awceng.com .....
Page 15
A.1%
`/M
5. Set up basic hydraulic model to analyze the roadside ditches,culverts and
existing storm drainage system using Autodesk Storm and Sanitary
Analysis'"software. This will compute backwater analysis and show which
areas are out of bank full condition along with computed hydraulic grade
line.
6. Edit model to reflect trials of options for improvements to existing
system.
7. Review preliminary results with the city staff.
8. Prepare final report including Engineer's recommendation.
PROPOSED FEE AND SCHEDULE
For the services rendered,we propose a maximum fee not to exceed Twenty-
Two Thousand Nine Hundred Seventy-Five Dollars($22,975.00). Upon
authorization and notice to proceed,we expect to complete this work within 120
working days,unless delayed by weather or circumstances beyond our control.
Please let me know if you have any questions or concerns about the scope,fee
or schedule. We appreciate this opportunity to serve the City of Port Arthur.
Very truly yours,
ARCENEAUX WILSON&COLE LLC
Joe M.Wits ,Jr.,PE
President
Page 16
ATTACHMENT 3
__-,,,,,,, ARCEN-2 OP ID:BC
AGGRO CERTIFICATE OF LIABILITY INSURANCE
°x'E'""°°'.Y.'
1.--- Ofin 5/2017
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER.AND THE CERTIFICATE HOLDER.
IMPORTANT. If the certificate holder is an ADDITIONAL INSURED.the policy(ies)must be endorsed If SUBROGATION IS WAIVED.subject to
the terms and conditions of the policy,certain policies may require an endorsement A statement on this certificate does not confer rights to the
certificate holder in lieu of such endorsement(s).
PRODUCER CONTACT
Braud Vaughn&Williamson PHONE
Bonnie R Cobum ACSR ����
Insurance Agency Ic No EOL 409-833-8621 IWC.Mel: -
P 0 Box 5389L
Beaumont.TX 77726 ADatEss
Braud.Vaughn.Williamson _ INSURER(S)AFFORDING COVERAGE IAN:r__
SOURER Texas Mutual Insurance Co. 525190
INSURED Arceneaux Wilson&Cole LLC INSURER a United Fire Lloyds __ __
13021
2901 Turtle Creek Dr Suite 320 INSURER C.Evanston Insurance Co. 35378
Port Arthur,TX 77642 -
INSURER 0•Underwriters at Lloyds ___
'
INSURER E.
INSURER F: I
COVERAGES CERTIFICATE NUMBER: REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWRHSTANDWG ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO AU.THE TERAS.
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR
TYPE OF INSURANCE AMA SUR POLICY LEE POLICY EXP
1NS0 WIND POLICY NUMBER (M WDOWYYY)(MMDOO/YYYYI UMTS
B X COIWERCIAL GENERAL LUINUTY EACH OCCURRENCE s 1.000,000
I CLAfI,.SAIADE ❑X OCCUR X X 85319667 08/20/2017108/20/2018 DAMM.ETOREN hED 100,000
PREMISES IEa gKVrNHYI s
MED EXP(My on.Person S 5,000
PERSONAL a ADV INJURY _s 1,000,000
-
GEM AGGREGATE LIMIT APPLES PER GENERAL AGGREGATE s 2,000,000
POLICY❑, ❑LOC PRODUCTS-COMP/OP AGO s 2.000,000
OTHER: s
AUTOYOIWE UAea/TY lEa"eNABINEO SINGLE LSAT s 1,000.000
B X ANY AUTOX X 85319867 06/2012017 08120/2018 sow.,oaken(Per p.mon) s
ALL OWNED SCHEDULED BODILY INJURY Pet+ctldull $ _
_
AUTOS AUTOS
NON-OWNED sOPERTYIDAMAGE s ,
HIRED AUTOS -_AUTOS
S
X UYBREw Luc X oCCUT EACH OCCURRENCE s 9,000,000
EXCESS LIAe CLAASSMADE X X 85319867/16EFXMS80859 08/20/2017 08120/2016 AGGREGATE s 9,000,000
DEO I I RE7ENTION5 S
WORKERS COMPENSATION X I$T�ATUTE l 1 ERµ
SI
AND EMPLOYERS'LIAUTY
A ANY PROPRIETORPARTNEREIECUTNE YIN X TSF0001274566 08/21/2017 08/21/2016 EL EACH ACCIDENT s 1,000,000
OFFICER'MEMBER EXCLUDED, ❑NIA
(Mandatory in NH) E L DISEASE-EA EMPLOYEE S 1,000,000
Ryes dearwewor
DESCRIPTION OF OPERATIONS ON.. E L DISEASE-POLICY LAW S 1,000,000
D Professional Liab ANE147633317 08/20/2017 08/20/2018 Each Ckn 2,000,000
Aggregate 2,000,000
1
D ESCRPTIOII OF OPERATIONS I LOCATIONS I VEHICLES(ACORD 101.Addmonel Wreaths Schedule.may be attached If mer.Niece I.required)
•*•see Holder Notes
CERTIFICATE HOLDER CANCELLATION _____
CITYP-3
SHOULD ANT OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL 8E DELIVERED IN
City of Port Arthur ACCORDANCE WITH THE POLICY PROVISIONS.
PO Box 1089
Port Arthur,TX 77641 nu r HORZED REPRESENTATIVE
15 1988.2014 ACORD CORPORATION. All rights reserved.
ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD
Page 17
NOTEPAD: HOLDER CODE CITYP-3 ARCEN-2 PAGE 2
wwREas RAPE Arceneaux Wilson&Cole LLC OP ID:BC D•�• 08/15/2017
e policies (except workers compensation) include a blanket automatic
additional insured endorsement that provides additional insured status to
the certificate holder, City of Port Arthur, when there is a written
contract between the named insured and the certificate holder, City of
Port Arthur, that requires such status.
'The policies include a blanket automatic waiver of subrogation
endorsement that provides this feature only when there is a written
contract between the named insured and the certificate holder, City of
Port Arthur, that requires it
30 Day Notice of Cancellation Applies.
Page 18
fix aux
04111
1
.' ARCENEAUX WILSON 8c COLE
engineering surveying planning
February 19, 2018
Mr. Armando Gutierrez, PE
Director of Public Works
City of Port Arthur
PO Box 1089
Port Arthur, Texas 77641-1089
RE: Proposal for Preliminary Engineering Drainage Study
For Vista Village, Port Arthur, Texas
Dear Mr. Gutierrez:
Thank you for contacting us to review the drainage concerns in the Vista Village
Subdivision. Based on our field visit we will be focusing our drainage study in the
area bound by Pine Avenue, Maple Avenue to the west and south and 60th Street
and Roosevelt Avenue to the north and east. The study will go beyond a
"desktop" study of available records, to include limited field data collection and
inventory of systems serving the vicinity. Fort this project,we propose the
following Scope of Services:
SCOPE OF SERVICES
1. Research and assemble available records relating to drainage from the
City, Jefferson County Drainage District 7, TxDOT and the US Army Corps
of Engineers.
2. Determine or verify contributing drainage area to subject area using maps
and field confirmation.
3. Perform surveyed cross sections along roads within the drainage area and
inventory driveway culverts.
4. Plot a contour and drainage area map of the subject area showing limited
topography.
409.724.7888
2901 Turtle Creek Dr,Suite 320
Port Arthur.TX 77642 Engineering Surveying
awceng.com
Afix civic
vidly
5. Set up basic hydraulic model to analyze the roadside ditches, culverts and
existing storm drainage system using Autodesk Storm and Sanitary
Analysis' software. This will compute backwater analysis and show which
areas are out of bank full condition along with computed hydraulic grade
line.
6. Edit model to reflect trials of options for improvements to existing
system.
7. Review preliminary results with the city staff.
8. Prepare final report including Engineer's recommendation.
PROPOSED FEE AND SCHEDULE
For the services rendered, we propose a maximum fee not to exceed Twenty-
Two Thousand Nine Hundred Seventy-Five Dollars ($22,975.00). Upon
authorization and notice to proceed,we expect to complete this work within 120
working days, unless delayed by weather or circumstances beyond our control.
Please let me know if you have any questions or concerns about the scope, fee
or schedule. We appreciate this opportunity to serve the City of Port Arthur.
Very truly yours,
ARCENEAUX WILSON & COLE LLC
Joe M. Wilso., Jr., PE
President
H
a)
0)
as
a
JP JP
0 0
0 0
0
H
0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 00
0 0
0 0
0 0
N N
H
0 M 0
o N 4) 4) a)
N H O 0 U
o ,. ro
o -4 44 CD
u -44 4) .4i um
H� bteCN 0WA
)a) 0
0.
ni
0 0,0 p,--i x aa)i C 003 ami
z CD 0 44 til
a) U d
45 a 41 Nd q
0NXil W0 O 0 p
)., -. CO a) a) CO 0) 4)rl U
ao > 10 a ° 0)D •.40a .uam :
.i ). 1 S.100(. 0001. 00
o . 01:40›, 43 pa Ep
0,F1 N
0 •
N H
N-.+m
.. -4 111
al 1, 1
OQ 1.w
b o
Y (V 0 0 0 0 0 0 0 0 0 0 0 0 a)
q q.-i o 00000000000 0
O co.-1 a) .-1 U
U H O a1 0 HfA
O U 0 ,10) U ,C (4 W
.-1 0 01
0 O a'
c. F�E W
�j 2pp N
o PX zaz
H Si 01 a0 000
a 000 .O. a 0 z En
.
W o o o 0 0 0 0 0 0 0 0 0 0 0 0 01 404000
V] O O O O O O O O O O O O 0 014 H Z-,H H W
o O • • • • • • • • • 4) W.]H.].7 W
4 o o °w43 a CO
z a) a) 0 044Qaaa
O H .-i (-1 a) 0
0 4)) 'g 1t 0 4 n
v) U O
r W 041 U -.. 44 0)
CV W 4 0y .y b a rl.-1 cv a m .-4 0
.•1 0X co 0 PI --1 0 b o•-)o,n ,n o
.. qao o
hg4 a+
10 CV .1 Y, a
0
o• ak gzm Uc1.1 CP A > 1 °
01
0 1) 4)
u4w . 'u ° 0 m4> �o � roN• Q4 44 >, " Fl 0 ). a >,aw
1,
EE uuUyyW1y \ 044NNP0ay °
Z 04 .. u. q00 000 0P,0004) p • fA a >
¶ H m a)-.. C oozakXa45�i ha m o of qa 4 0 >,•.
a) 0 4J P.E 40 4-1.1.3 1.4 -. u'd u it L e 0 u u
1,
14 r0 Hpu
P oWpay 0HW
,o)$4 P, U •n O Pi o 00000004.4 > RN-44-.i E
Wgg
aaa 4 Pia" Ig a ii 0,• CPWA•Qa41WO
EXHIBIT B
Exhibit A
Total of 14 pages
THE STATE OF TEXAS §
COUNTY OF JEFFERSON §
CONTRACT
FOR PROFESSIONAL SERVICES
(NON-FEDERAL FORM)
PARTI - AGREEMENT
THIS AGREEMENT, entered into as of this day of , 2018 by and
between the City of Port Arthur,Port Arthur,Texas(hereinafter called the"CITY")acting herein by
its City Manager,hereunto duly authorized and Arceneaux Wilson&Cole LLC (hereinafter called
the"ENGINEER")acting herein by Joe M.Wilson,Jr.,PE,its President, hereunto duly authorized:
WITNESSETH THAT:
WHEREAS, the CITY desires to engage the Engineer to (1) render certain technical and
professional services hereafter described in"Scope of Services"or(2)perform certain work hereafter
described in "Scope of Services": NOW, THEREFORE, the Parties hereto do mutually agree as
follows:
1. EMPLOYMENT OF ENGINEER
The CITY hereby agrees to engage the ENGINEER and the ENGINEER hereby agrees to
perform the "Scope of Services"hereinafter set forth. This contract shall be performed in
Jefferson County,Texas.
2. SCOPE OF SERVICES
A. BASIC SERVICES
Engineering services in connection with the following described project,to wit:
Preliminary Engineering for Drainage Study
North Port Acres Area (67th St./Garnet Ave.)
AWC Project No. CPA-945
ENGINEER'S compensation for Basic Services shall be as set forth in Paragraph 5.
Page 1
The services rendered by.ENGINEER for the Project to be designed for construction are divided into
three(3) distinct and sequential phases as follows:
1. Preliminary Phase—Preliminary studies, layouts, and cost estimates
2. Design Phase Preparation of plans, specifications-and eentract documents
3. Construction Phase CITY'S representative during bidding and construction
Certain elements of the engineering work are covered under the Basic Services; others are
performed as Additional Services. Those elements of the engineering work which cannot be
accurately predetermined or controlled entirely by the ENGINEER are performed as
Additional Services.
These phases are expanded in the following outline:
A. BASIC SERVICES
1. PRELIMINARY PHASE
(a) Provide Project Management services to direct,supervise and coordinate the
various items of work within this Phase, including review of activities of
subcontracted engineers.
(b) Attend preliminary conference with the CITY and other interested parties
regarding the project in order to further define the work.
(c) Establish the scope of any soil and foundation investigations or any special
surveys and tests which,in the opinion of the ENGINEER,may be required,
and arrange for such work to be done, for the CITY'S account.
(d) Prepare layouts, cost estimates, studies and documentation as described in
attached Proposal shown in Exhibit 1.
2. DESIGN PHASE
- - - - - .; - - - , . - . - -- -•-. - -
. .
subcontracted e e j
., . - •-., .. - .• . . - _ h - - * .
required for design, and arrange for such work to be done, for the CITY'S
aeeeunt:
(c) Furnish to the CITY,where required by the circumstances of the assignment,
• .-- •. ._... _ . _ . _ . - . :, fer planning
advances).
Page 2
CITY.
I .. - -- .. _. _ -- - ` _ I` - - '
estimates that will reflect current, local construction cot.-As.
- . - - - ., -- - .. .. . e. .. -
_ • - . . .. .. - . --. . _ -- , . . . . . . -
3. CONSTRUCTION PHASE
subcontracted engineers. ##
(b) Assist the CITY in the advertisements of the project for bids.
(c) Assist the CITY in the opening and tabulation of bids for construction of the
the engineering considerations involved.
(d) Assist in the preparation of formal Contract Documents.
(when required by CITY) to insure that complete, accurate construction
and quality of work done by the Contractor arc consistent with the Contract
Documents.
b.) Provide services of a Resident Project Representative and other field
construction records, reports and information to the ENGINEER or Project F:
Engineer.
• j
(g) Arrange for construction testing as required by the Project, for the CITY'S
account.
Page 3
the CITY'S designated representative with a.11 facts germane to such matters
decision of the CITY, the ENGINEER shall be notified of the CITY'S
Contractor is to review and stamp his approval on submittals prior to
(k) Conduct, in company with the CITY, a final inspection of the Project for
Contractor.
ENGINEER'S compensation for Basic Services shall be as set forth in Paragraph 5.
Page 4
B. ADDITIONAL SERVICES
All work performed by ENGINEER at request of CITY which is not included in the
Basic Services defined above,shall constitute Additional Services. Unless included in said
Basic Services,Additional Services may include but are not limited to the following:
(1) Studies,tests,and process determination to establish basis of design for water
and waste treatment facilities.
(2) Land surveys and establishment of boundaries and monuments. and related
office computation and drafting.
(3) Preparation of property or easement descriptions.
(4) Preparation of any special reports required for marketing of bonds.
(5) Small design assignments (estimated construction cost less than
$100,000).
(6) Appearances before regulatory agencies.
(7) Assistance to the CITY as an expert witness in any litigation with third
parties, arising from the development or construction of the Project,
including preparation of engineering data and reports.
(8) Special investigations involving detailed consideration of operation,
maintenance and overhead expenses;preparation of rate schedules;
earnings and expense statements; special feasibility studies; appraisals;
evaluations; and material audits or inventories required for certification of
force account construction performed by the CITY.
(9) Special soil and foundation investigations, including field and laboratory
tests, borings,related engineering analyses,and recommendations.
(10) Detailed mill, shop and/or laboratory inspection of materials or equipment.
(11) Travel and subsistence required of the ENGINEER and authorized by the
CITY to points other than CITY'S or ENGINEER'S offices and Project
site.
(12) Additional copies of reports over ten(10) sets and additional sets of
Contract Document over twenty(20)sets.
(13) Preparation of applications and supporting documents for government
grants or planning advances for public works projects.
(14) Preparation of environmental statements and assistance to CITY in
preparing for, and attending public hearings.
(15) Plotting, computing, and filing plats of subdivisions; staking of lots; and
related land planning and partitioning functions. !i!
(16) Revision of contract drawings after a definite plan has been approved by
the CITY, redrawing of plans to show work as actually constructed.
(17) Services after issuance of Certificate of Completion.
(18) Services to investigate existing conditions or facilities or to make
measured drawings thereof, or to verify accuracy of drawings or other
information furnished by Client.
(19) Preparation of operating instructions and manuals for facilities and
training of personnel and assistance in operation of facilities.
Page 5
(21) Additional or extended services during construction made necessary by
work damaged by fire or other cause during construction,defective or
neglected work of contractor;services rendered after prolongation of
scheduled construction contract time by more than 5%,acceleration of
work schedule involving services beyond normal working hours; or default
under construction contract due to delinquency or insolvency.
(22) Providing any other service not otherwise included in this Agreement or
not customarily furnished in accordance with generally accepted
engineering practice.
(23) Any other special or miscellaneous assignments specifically authorized by
CITY.
ENGINEER'S compensation for Additional Services shall be as set forth in Paragraph 5.
3. TIME OF PERFORMANCE
ENGINEER will proceed immediately upon execution of this Contract with performance of
the services called for under the Basic Services with completion within 120 days after execution,
unless delayed by causes outside the control of ENGINEER,and will proceed with subsequent work
only on authorization by CITY. ENGINEER shall immediately submit to CITY in writing evidence
of delay satisfactory to the CITY Engineer's reasonable discretion,upon which an extension of time
equal to the period of actual delay shall be granted in writing.
4. INFORMATION AND SERVICES TO BE FURNISHED ENGINEER
It is agreed that the CITY will furnish, without charge, for the use of the Contract
information,data,reports,records,and maps as are existing,available,and necessary for the carrying
out of the work of the ENGINEER as outlined under "Scope of Services." The CITY and its
agencies will cooperate with the ENGINEER in every way possible to facilitate the performance of
the work described in this Contract.
5. COMPENSATION AND METHOD OF PAYMENT
A. COMPENSATION
CITY will pay ENGINEER for work performed and services rendered under
Paragraph 2"Scope of Services",(Basic Services and Additional Services)at the following
rates. It is agreed that total fees for Basic Services (including subcontracted engineering
services as described herein)under this Contract,as defined in Paragraph 2A and based on
the preceding schedule, shall be Forty-Three Thousand Six Hundred Eighty Dollars
($43,680.00) and shall be paid in increments based on monthly invoices. Additional
Services authorized in writing by the CITY will be compensated based upon hourly rates
established by the ENGINEER as shown in Attachment 2.
Page 6
B. PAYMENT
ENGINEER will invoice CITY Monthly for its services and charges incurred by
ENGINEER for subcontracted engineering services performed under the direction and
control of ENGINEER as described herein.
CITY agrees to pay ENGINEER at his office the full amount of each such invoice
upon receipt or as otherwise specified in this Agreement.A charge of one percent per month
shall be added to the unpaid balance of invoices not paid within 31 days after date of invoice.
The engineer shall pay any subcontractors no later than the tenth day after he receives
payment as required under Chapter 2251 Government Code of the Revised Civil Statutes of
Texas.
6. RECORDS
ENGINEER shall keep accurate records, including time sheets and travel vouchers, of all
time and expenses allocated to performance of Contract work. Such records shall be kept in the
office of the ENGINEER for a period of not less than five(5)years and shall be made available to
the CITY for inspection and copying upon reasonable request.
7. OWNERSHIP OF DOCUMENTS
All documents,including original drawings,estimates,specifications,field notes and data are
property of CITY. ENGINEER may retain reproducible copies of drawings and other documents.
All documents, including drawings and specifications prepared by ENGINEER are
instruments of service in respect to the project.They are not intended or represented to be suitable
for reuse by CITY or others on extensions of the Project or on any other project. Any reuse without
written verification or adaption by ENGINEER for the specific purpose intended will be at CITY'S
sole risk and without liability or legal exposure to ENGINEER and CITY shall indemnify and hold
harmless ENGINEER from all claims, damages, losses and expenses including attorneys' fees
arising out of or resulting therefrom. Any such verification or adaption will entitle ENGINEER to
further compensation at rates to be agreed upon by CITY and ENGINEER.
S. INSURANCE
All insurance must be written by an insurer licensed to conduct business in the State of Texas, f
unless otherwise permitted by Owner. The ENGINEER shall, at his own expense, purchase,
maintain and keep in force insurance that will protect against injury and/or damages which may arise
out of or result from operations under this contract,whether the operations be by himself or by any
subcontractor or by anyone directly or indirectly employed by any of them,or by anyone for whose
acts any of them may be liable,of the following types and limits(no insurance policy or certificate of
insurance required below shall contain any aggregate policy year limit unless a specific dollar
amount(or specific formula for determining a specific dollar amount)aggregate policy year limit is
expressly provided in the specification below which covers the particular insurance policy or
certificate of insurance).
Page 7
I. Standard Worker's Compensation Insurance(with Waiver of Subrogation in favor of
the CITY of Port Arthur, its officers, agents and employees.)
2. Commercial General Liability occurrence type insurance. (No "XCU" restrictions
shall be applicable.) Products/completed operations coverage must be included,and
the CITY of Port Arthur, its officers, agents and employees must be named as an
additional Insured.
a. Bodily injury $500,000 single limit per occurrence or $500,000 each
person/$500,000 per occurrence.
b. Property Damage$100,000 per occurrence.
c. Minimum aggregate policy year limit$1,000,000.
3. Commercial Automobile Liability Insurance(including owned,non-owned and hired
vehicles coverage).
a. Minimum combined single limit of$500,000 per occurrence for bodily injury
and property damage.
b. If individual limits are provided minimum limits are $300,000 per person,
$500,000 per occurrence for bodily injury and $100,000 per occurrence for
property damage.
4. Contractual Liability Insurance covering the indemnity provision of this contract in
the same amount and coverage as provided for Commercial General Liability Policy,
specifically referring to this Contract by date,job number and location.
5. ENGINEER also agrees to maintain Professional Liability Insurance coverage of
$250,000 minimum per occurrence/claim/policy year aggregate limits against
ENGINEER for damages arising in the course of, or as a result of, work performed
under this Contract. Coverage shall continue for a minimum of two(2)years after the
ENGINEER'S assignment under this Contract is completed.Additional Professional
Liability Insurance required is $0
ENGINEER shall cause ENGINEER'S insurance company or insurance agent to fill in all
information required (including names of insurance agencies, ENGINEER and insurance
companies,and policy numbers,effective dates and expiration dates) and to date and sign and do
all other things necessary to complete and make into a valid certificate of insurance the
CERTIFICATE OF INSURANCE Form attached to and made a part of this Contract, and
pertaining to the above listed Items 1,2,3,4, and 5; and before commencing any of the work and
within the time otherwise specified, ENGINEER shall file said completed Form with the CITY.
None of the provisions in said Form shall be altered or modified in any respect except as herein
expressly authorized. Said CERTIFICATE OF INSURANCE Form contains a provision that
coverages afforded under the policies will not be altered, modified or cancelled unless at least
fifteen(15)days prior written notice has been given to the CITY. ENGINEER shall also file with
the CITY valid CERTIFICATE(s)OF INSURANCE on like form from or for all Subcontractors
and showing the Subcontractor(s) as the Insured. Said completed CERTIFICATE OF
INSURANCE Form(s) shall in any event be filed with CITY not more than ten (10) days after
Page 8
execution of this Contract.
approved by the Owner.
9. PROFESSIONAL LIABILITY
A. ENGINEER shall be responsible for the use and employment of reasonable skill and
care befitting the profession in the designs,drawings,plans,specifications,data,reports and
designation of materials and equipment provided by ENGINEER for the Project covered by
this Contract. Approval by CITY shall not constitute nor be deemed a release or waiver of
the responsibility and liability of ENGINEER for the accuracy and competency of such
designs, drawings, plans, specifications, data, reports and designation of materials and
equipment. Contractor will be responsible for the actual supervision of Construction
operations and safety measures involving the work, his employees and the public, but the
ENGINEER will advise the Contractor of any items requiring the attention and action of the
Contractor.
B. If services include periodic visits to the site to inspect work performed by another
Contractor,ENGINEER is responsible for exercising reasonable care and skills befitting the
profession to assure that the Contractor performs the work in accordance with Contract
Documents and to safeguard the CITY against defects and deficiencies in the work;provided,
however, ENGINEER does not guarantee or insure the work completed by the Contractor.
During visits to the construction site, and on the basis of the ENGINEER'S on-site
observations as an experienced and qualified design professional, he will keep the CITY
informed on the extent of the progress of the work, and advise the CITY of material and
substantial defects and deficiencies in the work of material and substantial defects and
deficiencies in the work of Contractors which are discovered by the ENGINEER or otherwise
brought to the ENGINEER'S attention in the course of construction,and may,on behalf of
the CITY exercise whatever rights the CITY may have to disapproved work and materials as
failing to conform to the Contract Documents.
C. In connection with the services of Resident Project Representatives,ENGINEER will
p
use the usual degree of care and prudent judgement in the selection of competent Project
Representatives, and the ENGINEER will use its best efforts to see that the Project
Representatives are on the job to perform their required duties. In performing these duties
and services (described in this sub-paragraph), ENGINEER is responsible for exercising
reasonable care and skill befitting the profession the assure that the Contractor performs the
work in accordance with Contract Documents and to safeguard the CITY against defects and
deficiencies in the work; provided,however, ENGINEER does not guarantee or insure the
work completed by the Contractor.
i
D. In performing these services the ENGINEER will at all times endeavor to protect the
CITY on the Project and work sites and safeguard the CITY against defects and deficiencies
Page 9
in the work of the Contractor;provided,however,ENGINEER does not guarantee or insure
the work completed by the Contractor, nor is ENGINEER responsible for the actual
supervision of construction operations or for the safety measures that the Contractor takes or
should take.
E. ENGINEER shall not be responsible for any excess of construction costs over an
amount estimated.
10. INDEMNIFICATION
ENGINEER shall comply with the requirements of all applicable laws,rules,and regulations
in connection with the services of ENGINEER and shall exonerate,indemnify and hold harmless the
CITY,its officers,agents and all employees from any and all liability,loss or damage arising out of
noncompliance with such laws,rules and regulations;without limitation,ENGINEER shall assume
full responsibility for payments of Federal, State and Local taxes or contributions imposed or
required under the Social Security,Worker's Compensation,and Income Tax Laws with respect to
ENGINEER'S employees. Further,ENGINEER shall exonerate,indemnify and hold harmless the
CITY, its officers, agents and all employees from any and all liability, loss,damages, expenses or
claims arising out of negligence of ENGINEER, its officers, agents and employees in connection
with any of the work performed or to be performed under this Contract by ENGINEER or as a result
of ENGINEER'S failure to use and employ reasonable skill and care befitting the profession in
accordance with paragraph 9 hereof. Further, ENGINEER shall exonerate, indemnify and hold
harmless the CITY,its officers,agents,and all employees from any and all liability, loss,damages,
expenses or claims for infringement of any copyright or patents arising out of the use of any plans,
design, drawings,or specifications furnished by ENGINEER in the performance of this Contract.
•
The foregoing indemnification provision shall apply to ENGINEER regardless of whether or not said
liability,loss,damages,expenses, or claims is caused in part by a party indemnified hereunder.
11. ADDRESS OF NOTICE AND COMMUNICATIONS
CITY: ENGINEER:
Harvey Robinson Arceneaux Wilson& Cole LLC
Interim City Manager 2901 Turtle Creek Dr., Suite 320
City of Port Arthur Port Arthur, Texas 77642
PO Box 1089 ATTN: Joe M. Wilson, Jr., PE
Port Arthur, Texas 77641-1089
All notices and communications under this Contract shall be mailed or delivered to CITY and
ENGINEER at the above addresses.
Page 10 •
12. CAPTIONS
Each paragraph of this Contract has been supplied with a caption to serve only as a guide to
the contents. The caption does not control the meaning of any Paragraph or in any way determine its
interpretation or application.
13. SUCCESSORS AND ASSIGNMENTS
The CITY and the ENGINEER each binds himself and his successors, executors,
administrators, and assigns to the other party of this Contract and to the successors, executors,
administrators and assigns of such other party,in respect to all covenants of this Contract. Except as
above, neither the CITY nor the ENGINEER shall assign, sublet, or transfer his interest in this
Contract without the written consent of the other. Nothing herein shall be construed as creating any
personal liability on the part of any officer or agent of any public body which may be a party hereto.
14. TERMINATION OF CONTRACT FOR CAUSE
If, through any cause, the ENGINEER shall fail to fulfill in timely and proper manner his
obligations under this Contract,or if the ENGINEER shall violate any of the covenants,agreements,
or stipulations of this Contract,the CITY shall thereupon have the right to terminate this Contract by
giving written notice to the ENGINEER of such termination and specifying the effective date
thereof,at least five(5)days before the effective date of such termination. In such event,all finished
or unfinished documents,data, studies, survey, drawings, maps, models, photographs, and reports
prepared by the ENGINEER under this Contract shall,at the option of the CITY,become its property
and the ENGINEER shall be entitled to receive just and equitable compensation for any work
satisfactorily completed hereunder.
Notwithstanding the above,the ENGINEER shall not be relieved of liability to the CITY for
damages sustained by the CITY by virtue of any breach of the Contract by the ENGINEER and the
CITY may withhold any payment to the ENGINEER for the purpose of setoff until such time as the
exact amount of damages due the CITY from the ENGINEER is determined.
15. TERMINATION FOR CONVENIENCE OF THE CITY
The CITY may terminate this Contract at any time by giving at least thirty(30)days notice in
writing to the ENGINEER. If the Contract is terminated by the CITY as provided herein, the
ENGINEER will be paid for the time provided and expenses incurred up to the termination date. If
this Contract is terminated due to the fault of the ENGINEER, Paragraph 14 hereof relative to
termination shall apply.
16. CHANGES
The CITY may, from time to time, request changes in the scope of the services of the
ENGINEER to be performed hereunder. Such changes, including any increase or decrease in the
amount of the ENGINEER'S compensation, which are mutually agreed upon by and between the
Page 11
CITY and ENGINEER shall be incorporated in written amendments to this Contract.
17. PERSONNEL
A. The ENGINEER represents that he has, or will secure at his own expense, all
personnel required in performing the services under this Contract. Such personnel
shall not be employees of or have any contractual relationship with the CITY.
B. All of the services required hereunder shall be performed by the ENGINEER or
under his supervision and all personnel engaged in the work shall be fully qualified
and, if applicable shall be authorized or permitted under State and local law to
perform such services.
C. None of the work or services covered by this Contract shall be subcontracted without
the prior written approval of the CITY. Any work or services subcontracted
hereunder shall be specified by written Contract or agreement and shall be subject to
each provision of this Contract.
18. REPORTS AND INFORMATION
The ENGINEER at such times and in such forms as the CITY may require,shall furnish the
CITY such periodic reports s it may request pertaining to the work or services undertaken pursuant to
this Contract, the costs and obligations incurred or to be incurred in connection therewith,and any
other matters covered by this Contract.
19. CIVIL RIGHTS
Under Chapter 106 Civil Practice and Remedies Code of the Revised Civil Statutes of Texas,
no person shall, on the grounds of race, religion, color, sex or national origin, be excluded due to
discrimination under any program or activity of the CITY.
The ENGINEER will carry out its work under this Contract in a manner which will permit
full compliance by the CITY with the Statute.
20. INTEREST OF ENGINEER AND EMPLOYEES
The ENGINEER covenants that he presently has no interest and shall not acquire any interest,
direct or indirect,in the study area or any parcels therein or any other interests which would conflict
in any manner or degree with the performance of his services hereunder.
The ENGINEER further covenants that in the performance of this Contract,no person having
any such interest shall be employed.
Page 12
21. INCORPORATION OF PROVISIONS REQtiIRED BY LAW
Each provision and clause required by law to be inserted into the Contract shall be deemed to
be enacted herein and the Contract shall be read and enforced as though each were included herein.
If through mistake or otherwise any such provision is not inserted or is not correctly inserted, the
Contract shall be amended to make such insertion on application by either party.
EXECUTED IN TWO (2) counterparts (each of which is an original) on behalf of
ENGINEER by Joe M.Wilson,Jr.,PE,its President shown below,and on behalf of the CITY by its
City Manager.
is
ACCEPTED: PROPOSED AND AGREED TO:
CITY: ENGINEER:
Harvey Robinson Joe M. Wilson,Jr., PE
Interim City Manager Arceneaux Wilson& Cole LLC
DATE: DATE:
ATTEST ATTEST:
CITY Secretary
APPROVED AS TO FORM:
CITY Attorney
DATE:
Page 13
ARCENEAUX WILSON&COLE
eng,neenng i surveying I planning
February 14, 2018
Mr. Armando Gutierrez, PE
Director of Public Works
CITY OF PORT ARTHUR
PO Box 1089
Port Arthur, Texas 77641-1089
RE: PROPOSAL FOR PRELIMINARY ENGINEERING DRAINAGE STUDY
FOR NORTH PORT ACRES AREA (67TH STREET/GARNET AVE)
AWC PROPOSAL NO. CPA-945
Dear Mr. Gutierrez:
Thank you for contacting us to review the drainage concerns in Port Acres and
give you our proposal to conduct a preliminary engineering study. The study will
go beyond a "desktop" study of available records, to include limited field data
collection and inventory of systems serving the vicinity. Fort this project, we
propose the following Scope of Services:
SCOPE OF SERVICES
1. Research and assemble available records relating to drainage from the
City, Jefferson County Drainage District 7, TxDOT and the US Army Corps
of Engineers.
2. Determine or verify contributing drainage area to subject area using maps
and field confirmation.
3. Perform surveyed cross sections along roads within the drainage area and
inventory driveway culverts.
4. Plot a contour and drainage area map of the subject area showing limited
topography.
5. Establish 25-year rainfall criteria (per the City's request).
409.724.7888
2901 Turtle Creek Dr.Suite 320
Port Arthur,TX 77642 Engineering Surveying
awceng.com
A+...
vfly
6. Set up basic hydraulic model to analyze the roadside ditches, culverts and
outfalls using GeoHec-RasTM software. This will compute backwater
analysis and show which areas are out of bank full condition along with
computed hydraulic grade line.
7. Edit model to reflect trials of options for improvements. Improvement
options could involve a combination of culvert upgrades, large diameter
trunk line, additional pumping capacity at Rodair Gully Pump Station and
detention.
8. Prepare magnitude of probable construction cost for each option.
9. Review preliminary results with the city staff.
10. Prepare final report including Engineer's recommendation.
PROPOSED FEE AND SCHEDULE
For the services rendered,we propose a maximum fee not to exceed Forty-
Three Thousand Six Hundred Eighty Dollars ($43,680.00). Upon authorization
and notice to proceed, we expect to complete this work within 120 working days,
unless delayed by weather or circumstances beyond our control.
If all is in order, we can prepare a contract for Council consideration using this
proposal as an attachment to the contract. Please let me know if you have any
questions or concerns about the scope, fee or schedule. We appreciate this
opportunity to serve the City of Port Arthur.
Very truly yours,
ARCENEAUX WILSON & COLE LLC
Ronald J Arceneaux, PE, PLS
Corporate Secretary
H
0)
0
41
a
dP4
00
00
0
.I
0 0 0 0 0 0 0 0 0 0
0 0 0 0 0 0 0 0 0 0
0 0
0 0
0 0
.i .I
H
O 0) 0)
N 0) H UUp GU
>± 0 H 10 0i
0 .63co..I H N .I
H -.1 W'0 AE 0) 0 10
HC9 0)00000) Ogg
N• E mO �tv u aOi H n H
GI Cd o o 0,0
O• 0 Cd H 0 C H W O W
0 -.-'1 0 1 0) 10 0) 0.-I U
0 0.0 01••1 Irl 0O 1 0 Gi
• 0 110
HOC /400H> 0 0 Ha' /1 O 0
O
w O
COi G:U>.DW aF0
U •
OH.-I01
10•.I 01
.1 N
-)
V
O 1
010V
a
'O o
ar) N 0 0 0000 00 000 0 0)
O 0.+ 0 0 0 0 0 0 0 0 0 0 0 0 0
U• H O 16 -I-I co
O 00 -rim L) N 16 W
•C VI 0 10 0 HI CC1 C H
1-I L GI >
00 a
r
W
pZp 0
04 0 co 0
U Da aaz
H /4 0) WO 000
Wo o o -0. �I a (0 co
W o 0o 000000000000 '0 4040Om
VJ 000000000000 C' g H'j.H HW
O O • • • • • • • 0) 010).400W
0 a 0 0 g 0 a
4
zm CO L 00.00. 0.0.
O .I .-I .-I 0) U
CO H bL 4)
C.2 1d .0m 0
a, 0
0 W •.I O •.I H N
N W .i M R 'O a .IHN C MH VI 0
Om C 44o oM mo
COo -ry 0 I■°y am 0 Li
---.WW 000) '0 bH .10{ 0AEE00S.'.-I MO 0 t0 10a 10 m >.
NFF 0M --440) (00 10 H > UpZ000q.OHi O) >.C.-4i b)W 04, Wpp U 00) 1�(0 H .0--Ii
G W 4 b U O 0) O 0) 0f 010 P 0 O Cd •.I H 01 RI C >
0x1' �Hrtv--+ 0 00Z )' CX(Xbb40 0
0) E 0 L.7 U 0 444.) aI -.I 1J'0 Hat ai 44 4.10 ›,-4 01�)-yam)H
H NH ID—loons
01'0 E.I 00 0 H 010 PG Q1 H•.I-100H
O H 20'J-.I o O Cd GI O d.I N m?N lO N 001 O.1 N )) O W H N > 0) QI 0
OO)H a W 0U0 •}r(-o 0Ooo00000O.1.1.1 g.> ppa ►�.II p, '0q0)•.+-.1 Aq E0
O 00 U 00 U a0.0 4 }I aa
H R as
0. W ill NWOr]d,NWO