Loading...
HomeMy WebLinkAboutPR 22727: CONTRACT WITH SCHAUMBURG & POLK, INC., PROJECT ENGINER FOR THE DALLAS & 4TH ELEVATED STORAGE TANK REHABILITAITON dJ „r; rtfrur Iesus INTEROFFICE MEMORANDUM -WATER UTILITIES DEPARTMENT- Date: August 3, 2022 To: The Honorable Mayor and City Council Through: Ronald Burton, City Manager From: Calvin Matthews, P.E., Water Utilities Director RE: PR 22727—Execution of a contract with Schaumburg&Polk, Inc. of Beaumont, Texas for Professional Services Rendered as Project Engineer for the Dallas & 4th Elevated Storage Tank Rehabilitation Introduction: The intent of this Agenda Item is to seek City Council's approval for the City Manager to execute a contract with Schaumburg & Polk, Inc. (SPI) of Beaumont, Texas, for Professional Services rendered as Project Engineer for the Dallas & 4th Elevated Storage Tank (EST) Rehabilitation Project. SPI was selected from one of the pre-qualified engineering firms as approved by Resolution No. 22-113 to work on this project. Background: The elevated storage tank,located at Dallas&4th,is in need of pipe and valves design and repair. The City of Port Arthur needs a project engineer to design and oversee the duration of the project. SPI was selected as project engineer for the Dallas & 4th EST Rehabilitation Project because of their experience. This engineering firm will provide professional engineering services by preparing specifications and documents, bid procedures phase and the construction phase. Budget Impact: Professional services rendered as Project Engineer for the Dallas & 4th Elevated Storage Tank Rehabilitation Project has a projected budgetary impact of$42,200.00. Funding is available in City Account No. 405-40-000-8516-00-00-000, Project No. WS-0004 DES. Recommendation: It is recommended that City Council approve PR 22727, as discussed/outlined above. "Remember, we are here to serve the Citizens of Port Arthur" PR No. 22727 8/3/22 bw Page 1 of 3 RESOLUTION NO. A RESOLUTION AUTHORIZING THE CITY MANAGER TO ENTER INTO A CONTRACT WITH SCHAUMBURG & POLK, INC. OF PORT ARTHUR, TEXAS, FOR PROFESSIONAL SERVICES RENDERED AS PROJECT ENGINEER FOR THE DALLAS AVENUE & 4TH STREET ELEVATED STORAGE TANK REHABILITATION PROJECT WITH A PROJECTED BUDGETARY IMPACT OF $42,200.00; FUNDS ARE AVAILABLE IN ACCOUNT NO. 405-40-000-8516-00-00-000, PROJECT NO. WS-0004 DES. WHEREAS, the Elevated Storage Tank, located at Dallas &4th needs to be rehabilitated; and, WHEREAS, the City of Port Arthur is in need of a Project Engineer to oversee the duration of said project; and, WHEREAS, pursuant to Resolution No. 22-113, passed on March 21, 2022, City Council pre-approved five (5) engineering firms, which included Schaumberg & Polk of Beaumont, Texas, for the purposes of providing professional engineering services for the upcoming Water Utilities projects for a two-year term; and, WHEREAS, it is deemed in the best interest that Schaumburg & Polk, Inc. of Port Arthur, Texas, serve as project engineer for the Dallas Ave. & 4th St. Elevated Storage Tank Rehabilitation Project,with a projected budgetary impact of$42,200.00; and, WHEREAS, a copy of the contract is attached as Exhibit"A". NOW THEREFORE, BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF PORT ARTHUR: THAT,the facts and opinions in the preamble are true and correct; and, THAT, the City Manager is hereby authorized and directed to execute, on behalf of the City of Port Arthur, a contract, in substantially the same form as the attached Exhibit "A", with Schaumburg & Polk, Inc. of Port Arthur, Texas, for providing professional services, as Project PR No. 22727 8/3/22 bw Page 2 of 3 Engineer, relating to the Dallas Avenue & 4th Street Elevated Storage Tank Rehabilitation Project, with a projected budgetary impact of$42,200.00, contingent upon the notice to proceed; and, THAT, funding for this contract is in City Account No. 405-40-000-8516-00-00-000, Proj ect No. WS-0004 DES. THAT, a copy of the caption of this resolution be spread upon the minutes of the City Council. READ, ADOPTED, AND APPROVED, this day of , 2022, AD, at a Regular Meeting of the City Council of the City of Port Arthur, Texas by the following Vote: AYES: Mayor: Councilmembers: NOES: Thurman"Bill"Bartie Mayor ATTEST: Sherri Bellard City Secretary APPROVED_AS TO FORM: alecia Tize o City Attorney PR No. 22727 8/3/22 bw Page 3 of 3 APPROVED FOR ADMINISTRATION: Ronald Burton City Manager Mi - Calvin Matthews, '.E. Water Utilities Director APPROVED AS TO FUND AVAILABILITY: 4 c-v \-1) Kandy Danie Interim Finance Director Clifton Williams, CPPB Purchasing Manager EXHIBIT "A" STATE OF TEXAS § CITY OF PORT ARTHUR,TEXAS § AGREEMENT FOR PROFESSIONAL SERVICES COUNTY OF JEFFERSON § This Agreement for Professional Services("Agreement")is made by and between the City of Port Arthur,Texas,a Texas home-rule municipality located in Jefferson County,Texas("City"), and Schaumberg & Polk, Inc. ("Professional") (individually, each a "Party" and collectively, "Parties"), acting by and through the Parties' authorized representatives. Recitals: WHEREAS, City desires to engage the services of Professional as an independent contractor and not as an employee in accordance with the terms and conditions set forth in this Agreement; and WHEREAS, Professional desires to render professional services in accordance with the terms and conditions set forth in this Agreement. NOW, THEREFORE, in exchange for the mutual covenants set forth herein and other valuable consideration, the sufficiency and receipt of which is hereby acknowledged, the Parties agree as follows: Article I Employment of Professional Professional will perform as an independent contractor for all services under this Agreement to the prevailing professional standards consistent with the level of care and skill ordinarily exercised by members of Professional's profession, both public and private, currently practicing in the same locality under similar conditions including but not limited to the exercise of reasonable, informed judgments and prompt, timely action. If Professional is representing this it has special expertise in one or more areas to be utilized in the performance of this Agreement,then Professional agrees to perform those special expertise services to the appropriate local, regional and national professional standards. Article II Term 2.1 The term of this Agreement shall begin on the last date of execution hereof by all parties hereto (the "Effective Date") and shall remain in effect for an estimated (12) months or until services are complete, including the time necessary to develop the project deliverables, subject to change upon request or mutual agreement(s). 2.2 Professional may terminate this Agreement by giving thirty(30)days prior written notice to City. In the event of such termination by Professional, Professional shall be entitled to compensation for services satisfactorily completed in accordance with this Agreement prior to the date of such termination. 2.3 City may terminate this Agreement by giving ten (10) days prior written notice to Professional. In the event of such termination by City, Professional shall be entitled to compensation for services satisfactorily completed in accordance with this Agreement prior to the date of such termination. Upon receipt of such notice from City, Professional shall immediately terminate working on, placing orders or entering into contracts for supplies, assistance, facilities or materials in connection with this Agreement and shall proceed to promptly cancel all existing contracts insofar as they are related to this Agreement. 2.4 Upon notice of termination by Professional or City, Professional shall immediately surrender all project documents produced by Professional and its subcontractors up to and including the date on which termination notice was given. Article III Scope of Services 3.1 Professional shall perform the services specifically set forth in Exhibit A, attached hereto and incorporated herein by reference, entitled"Scope of Services." In case of conflict with the language of Exhibit A and the provisions of this Agreement, the provisions of this Agreement shall control. Any additional services require the prior approval of the City Council of the City. 3.2 The Parties acknowledge and agree that any and all opinions provided by Professional represent the best judgment of Professional. Article IV Schedule of Work 4.1 Professional agrees to commence services upon written direction from City and to complete the tasks set forth in Exhibit A, Scope of Services, in accordance with a work schedule established by City (the "Schedule"), which is attached hereto and incorporated as Exhibit A. 4.2 In the event Professional's performance of this Agreement is delayed or interfered with by acts of City or others, Professional may request an extension of time for the performance of same as hereinafter provided,and City shall determine whether to authorize any increase in fee or price, or to authorize damages or additional compensation as a consequence of such delays, within a reasonable time after receipt of Professional's request. 4.3 No allowance of any extension of time, for any cause whatsoever, shall be claimed or made by Professional, unless Professional shall have made written request upon City for such extension not later than five(5)business days after the occurrence of the cause serving as the basis for such extension request, and unless City and Professional have agreed in writing upon the allowance of such additional time. Page 2 of 11 City of Port Arthur, Texas Professional Services Agreement Article V Compensation and Method of Payment 5.1 City shall pay Professional for the services specifically as set forth in Exhibit A and in accordance with the Rate Schedule in an amount not to exceed $42,200.00 for said services. 5.2 Each month Professional shall submit to City an invoice supporting the amount for which payment is sought. Each invoice shall also state the percentage of work completed on the Project through the end of the then submitted billing period,the total of the current invoice amount, and a running total balance for the Project to date. 5.3 Within thirty (30) days of receipt of each such monthly invoice, City shall make monthly payments in the amount shown by Professional's approved monthly invoice and other documentation submitted. 5.4 Professional shall be solely responsible for the payment of all costs and expenses related to the services provided pursuant to this Agreement including, but not limited to, travel, copying and facsimile charges, reproduction charges, and telephone, internet, e-mail, and postage charges, except as set forth in Exhibit A. 5.5 Nothing contained in this Agreement shall require City to pay for any services that are unsatisfactory as determined by City or which is not performed in compliance with the terms of this Agreement, nor shall failure to withhold payment pursuant to the provisions of this section constitute a waiver of any right, at law or in equity, which City may have if Professional is in default, including the right to bring legal action for damages or for specific performance of this Agreement. Waiver of any default under this Agreement shall not be deemed a waiver of any subsequent default. Article VI Devotion of Time, Personnel, and Equipment 6.1 Professional shall devote such time as reasonably necessary for the satisfactory performance of the services under this Agreement. City reserves the right to revise or expand the scope of services after due approval by City as City may deem necessary, but in such event City shall pay Professional compensation for such services at mutually agreed upon charges or rates, a copy of the Rate Schedule is attached hereto as Exhibit A,and within the time schedule prescribed by City, and without decreasing the effectiveness of the performance of services required under this Agreement. In any event, when Professional is directed to revise or expand the scope of services under this Agreement, Professional shall provide City a written proposal for the entire costs involved in performing such additional services. Prior to Professional undertaking any revised or expanded services as directed by City under this Agreement, City must authorize in writing the nature and scope of the services and accept the method and amount of compensation and the time involved in all phases of the Project. Page 3 of 11 City of Port Arthur, Texas Professional Services Agreement 6.2 It is expressly understood and agreed to by Professional that any compensation not specified in this Agreement may require approval by the City Council of the City of Port Arthur and may be subject to current budget year limitations. 6.3 To the extent reasonably necessary for Professional to perform the services under this Agreement, Professional shall be authorized to engage the services of any agents, assistants, persons, or corporations that Professional may deem proper to aid or assist in the performance of the services under this Agreement. The cost of such personnel and assistance shall be borne exclusively by Professional. 6.4 Professional shall furnish the facilities, equipment,telephones,facsimile machines, email facilities, and personnel necessary to perform the services required under this Agreement unless otherwise provided herein. Article VII Relationship of Parties 7.1 It is understood and agreed by and between the Parties that in satisfying the conditions and requirements of this Agreement, Professional is acting as an independent contractor,and City assumes no responsibility or liability to any third party in connection with the services provided by Professional under this Agreement. All services to be performed by Professional pursuant to this Agreement shall be in the capacity of an independent contractor, and not as an agent, servant, representative, or employee of City. Professional shall supervise the performance of its services and shall be entitled to control the manner, means and methods by which Professional's services are to be performed, subject to the terms of this Agreement. As such, City shall not train Professional, require Professional to complete regular oral or written reports, require Professional to devote his full-time services to City, or dictate Professional's sequence of work or location at which Professional performs Professional's work, except as may be set forth in Exhibit A. Article VIII Insurance 8.1 Before commencing work, Professional shall, at its own expense, procure, pay for and maintain during the term of this Agreement the following insurance written by companies approved by the state of Texas and acceptable to City. Professional shall furnish to the City Manager certificates of insurance executed by the insurer or its authorized agent stating coverages, limits, expiration dates and compliance with all applicable required provisions. Certificates shall reference the project/contract number and be addressed as follows: City of Port Arthur, Texas Attention: Ronald Burton, City Manager 444 4th Street Port Arthur, Texas 77640-1089 Page 4 of 11 City of Port Arthur, Texas Professional Services Agreement A. Commercial General Liability insurance, including, but not limited to Premises/Operations, Personal & Advertising Injury, Products/Completed Operations, Independent Contractors and Contractual Liability, with minimum combined single limits of $500,000 per occurrence, $500,000 Products/Completed Operations Aggregate, and $500,000 general aggregate. Coverage must be written on an occurrence form. The General Aggregate shall apply on a per project basis. B. Workers' Compensation insurance with statutory limits; and Employers' Liability coverage with minimum limits for bodily injury: 1) by accident, $100,000 each accident, and 2) by disease, $100,000 per employee with a per policy aggregate of $500,000. C. Business Automobile Liability insurance covering owned, hired and non- owned vehicles, with a minimum combined bodily injury and property damage limit of $500,000 per occurrence. D. Professional Liability Insurance to provide coverage against any claim which the Professional and all professionals engaged or employed by the Professional become legally obligated to pay as damages arising out of the performance of professional services caused by error, omission or negligent act with minimum limits of$1,000,000 per claim, $1,000,000 annual aggregate NOTE:If the insurance is written on a claims-made form,coverage shall be continuous(by renewal or extended reporting period) for not less than thirty-six (36) months following completion of this Agreement and acceptance by City. 8.2 With reference to the foregoing required insurance, Professional shall endorse applicable insurance policies as follows: A. A waiver of subrogation in favor of City, its officials, employees, and officers shall be contained in the Workers' Compensation insurance policy. B. The City, its officials, employees and officers shall be named as additional insureds on the Commercial General Liability policy, by using endorsement CG2026 or broader. C. All insurance policies shall be endorsed to the effect that City will receive at least thirty (30) days notice prior to cancellation, non-renewal, termination, or material change of the policies. 8.3 All insurance shall be purchased from an insurance company that meets a financial rating of B+VI or better as assigned by A.M. Best Company or equivalent. Page 5 of 11 City of Port Arthur, Texas Professional Services Agreement Article IX Right to Inspect Records 9.1 Professional agrees that City shall have access to and the right to examine any directly pertinent books, documents, papers and records of Professional involving transactions relating to this Agreement. Professional agrees that City shall have access during normal working hours to all necessary Professional facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. City shall give Professional reasonable advance notice of intended audits. 9.2 Professional further agrees to include in subcontract(s), if any, a provision that any subcontractor agrees that City shall have access to and the right to examine any directly pertinent books, documents, papers and records of such subcontractor involving transactions related to the subcontract, and further, that City shall have access during normal working hours to all such subcontractor facilities and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this section. City shall give any such subcontractor reasonable advance notice of intended audits. Article X Miscellaneous 10.1 Entire Agreement. This Agreement and any and all Exhibits attached hereto constitutes the sole and only agreement between the Parties and supersedes any prior or contemporaneous understandings, written agreements or oral agreements between the Parties with respect to the subject matter of this Agreement. 10.2 Authorization. Each Party represents that it has full capacity and authority to grant all rights and assume all obligations granted and assumed under this Agreement. 10.3 Assignment. Professional may not assign this Agreement in whole or in part without the prior written consent of City. In the event of an assignment by Professional to which the City has consented, the assignee shall agree in writing with the City to personally assume, perform, and be bound by all the covenants and obligations contained in this Agreement. 10.4 Successors and Assigns. Subject to the provisions regarding assignment, this Agreement shall be binding on and inure to the benefit of the Parties and their respective heirs, executors, administrators, legal representatives, successors and assigns. 10.5 Governing Law and Exclusive Venue. The laws of the State of Texas shall govern this Agreement, and exclusive venue for any legal action concerning this Agreement shall be in a District Court with appropriate jurisdiction in Jefferson County, Texas. The Parties agree to submit to the personal and subject matter jurisdiction of said court. 10.6 Amendments. This Agreement may be amended only by the mutual written agreement of the Parties. Page 6 of 11 City of Port Arthur, Texas Professional Services Agreement 10.7 Severability. In the event any one or more of the provisions contained in this Agreement shall for any reason be held to be invalid, illegal, or unenforceable in any respect by a court of competent jurisdiction, such invalidity, illegality or unenforceability shall not affect any other provision in this Agreement,and this Agreement shall be construed as if such invalid, illegal, or unenforceable provision had never been contained in this Agreement. 10.8 Survival of Covenants and Terms. Any of the representations, warranties, covenants,and obligations of the Parties,as well as any rights and benefits of the Parties,pertaining to a period of time following the termination of this Agreement shall survive termination, including, but not limited to, Section 3.3,Article X, and, in particular, Sections 10.13 and 10.14. 10.9 Recitals. The recitals to this Agreement are incorporated herein. 10.10 Notice. Any notice required or permitted to be delivered hereunder may be sent by first class mail, overnight courier or by confirmed telefax or facsimile to the address specified below, or to such other Party or address as either Party may designate in writing, and shall be deemed received three (3) days after delivery set forth herein: If intended for City: City of Port Arthur, Texas 444 4th Street Port Arthur, Texas 77640 Attn: Ronald Burton, City Manager Copy to: City of Port Arthur, Texas 444 4th Street Port Arthur, Texas 77640 Attn: Val Tizeno, City Attorney If intended for Professional: Schaumberg & Polk, Inc. 1 Plaza Square, Suite 208 Port Arthur, Texas 77642 Attn: Steve Jordan 10.11 Counterparts. This Agreement may be executed by the Parties hereto in separate counterparts, each of which when so executed and delivered shall be deemed an original, but all such counterparts shall together constitute one and the same instrument. Each counterpart may consist of any number of copies hereof each signed by less than all, but together signed by all of, the Parties hereto. 10.12 Exhibits. The exhibits attached hereto are incorporated herein and made a part hereof for all purposes. Page 7 of 11 City of Port Arthur, Texas Professional Services Agreement 10.13 Professional's Liability. Acceptance of the Project Documents by City shall not constitute nor be deemed a release of the responsibility and liability of Professional,its employees, associates, agents or subcontractors for the accuracy and competency of their designs, working drawings, specifications or other documents and work; nor shall such acceptance be deemed an assumption of responsibility by City for any defect in the Project Documents or other documents and work prepared by Professional, its employees, associates, agents or sub-consultants. 10.14 Indemnification. PROFESSIONAL AGREES TO INDEMNIFY AND HOLD HARMLESS CITY FROM AND AGAINST ANY AND ALL LIABILITIES, DAMAGES, CLAIMS,SUITS,COSTS(INCLUDING COURT COSTS,REASONABLE ATTORNEY'S FEES AND COSTS OF INVESTIGATION)AND ACTIONS BY REASON OF INJURY TO OR DEATH OF ANY PERSON OR DAMAGE TO OR LOSS OF PROPERTY TO THE EXTENT CAUSED BY PROFESSIONAL'S NEGLIGENT PERFORMANCE OF SERVICES UNDER THIS AGREEMENT OR BY REASON OF ANY ACT OR OMISSION ON THE PART OF PROFESSIONAL, ITS OFFICERS, DIRECTORS, SERVANTS, AGENTS, EMPLOYEES, REPRESENTATIVES, CONTRACTORS, SUBCONTRACTORS, LICENSEES, SUCCESSORS OR PERMITTED ASSIGNS (EXCEPT WHEN SUCH LIABILITY, CLAIMS, SUITS, COSTS, INJURIES, DEATHS OR DAMAGES ARISE FROM OR ARE ATTRIBUTED TO THE NEGLIGENCE OF THE CITY). IF ANY ACTION OR PROCEEDING SHALL BE BROUGHT BY OR AGAINST CITY IN CONNECTION WITH ANY SUCH LIABILITY OR CLAIM, THE PROFESSIONAL, ON NOTICE FROM CITY, SHALL DEFEND SUCH ACTION OR PROCEEDINGS AT PROFESSIONAL'S EXPENSE, BY OR THROUGH ATTORNEYS REASONABLY SATISFACTORY TO CITY. PROFESSIONAL'S OBLIGATIONS UNDER THIS SECTION SHALL NOT BE LIMITED TO THE LIMITS OF COVERAGE OF INSURANCE MAINTAINED OR REQUIRED TO BE MAINTAINED BY PROFESSIONAL UNDER THIS AGREEMENT. IF THIS AGREEMENT IS A CONTRACT FOR ENGINEERING OR ARCHITECTURAL SERVICES, THEN THIS SECTION IS LIMITED BY, AND TO BE READ AS BEING IN COMPLIANCE WITH, THE INDEMNITY SPECIFIED IN § 271.904 OF THE TEXAS LOCAL GOVERNMENT CODE, AS AMENDED. THIS SECTION SHALL SURVIVE TERMINATION OF THIS AGREEMENT 10.15 Conflicts of Interests. Professional represents that no official or employee of City has any direct or indirect pecuniary interest in this Agreement. Any misrepresentation by Professional under this section shall be grounds for termination of this Agreement and shall be grounds for recovery of any loss, cost, expense or damage incurred by City as a result of such misrepresentation. 10.16 Default. If at any time during the term of this Agreement, Professional shall fail to commence the services in accordance with the provisions of this Agreement or fail to diligently provide services in an efficient, timely and careful manner and in strict accordance with the provisions of this Agreement or fail to use an adequate number or quality of personnel to complete the services or fail to perform any of Professional's obligations under this Agreement, then City shall have the right, if Professional shall not cure any such default after thirty (30) days written notice thereof, to terminate this Agreement. Any such act by City shall not be deemed a waiver Page 8 of 11 City of Port Arthur, Texas Professional Services Agreement of any other right or remedy of City. If after exercising any such remedy due to Professional's nonperformance under this Agreement, the cost to City to complete the services to be performed under this Agreement is in excess of that part of the contract sum which as not theretofore been paid to Professional hereunder, Professional shall be liable for and shall reimburse City for such excess costs. 10.17 Confidential Information. Professional hereby acknowledges and agrees that its representatives may have access to or otherwise receive information during the furtherance of Professional's obligations in accordance with this Agreement, which is of a confidential, non- public or proprietary nature. Professional shall treat any such information received in full confidence and will not disclose or appropriate such Confidential Information for Professional's own use or the use of any third party at any time during or subsequent to this Agreement. As used herein, "Confidential Information"means all oral and written information concerning the City, its affiliates and subsidiaries, and all oral and written information concerning City or its activities, that is of a non-public,proprietary or confidential nature including,without limitation,information pertaining to customer lists, services, methods, processes and operating procedures, together with all analyses,compilations, studies or other documents,whether prepared by Professional or others, which contain or otherwise reflect such information. The term "Confidential Information" shall not include such information that is or becomes generally available to the public other than as a result of disclosure to Professional, or is required to be disclosed by a governmental authority under applicable law. 10.18 Remedies. No right or remedy granted or reserved to the Parties is exclusive of any other right or remedy herein by law or equity provided or permitted; but each right or remedy shall be cumulative of every other right or remedy given hereunder. No covenant or condition of this Agreement may be waived without written consent of the Parties. Forbearance or indulgence by either Party shall not constitute a waiver of any covenant or condition to be performed pursuant to this Agreement. 10.19 No Third Party Beneficiary. For purposes of this Agreement, including the intended operation and effect of this Agreement, the Parties specifically agree and contract that: (1) this Agreement only affects matters between the Parties to this Agreement, and is in no way intended by the Parties to benefit or otherwise affect any third person or entity notwithstanding the fact that such third person or entity may be in contractual relationship with City or Professional or both;and(2)the terms of this Agreement are not intended to release,either by contract or operation of law, any third person or entity from obligations owing by them to either City or Professional. [The Remainder of this Page Intentionally Left Blank] Page 9 of 11 City of Port Arthur, Texas Professional Services Agreement EXECUTED this day of , 2022. CITY: CITY OF PORT ARTHUR,TEXAS, A Texas home-rule municipality, By: Ronald Burton, City Manager ATTEST: Sherri Bellard, City Secretary APPROVED AS TO FORM: Val Tizeno, City Attorney EXECUTED this day of , 2022. PROFESSIONAL: Schaumberg & Polk, Inc. By: , Owner/Consultant Page 10 of 11 City of Port Arthur, Texas Professional Services Agreement Exhibit A Scope of Services/ Schedule Page 11 of 11 City of Port Arthur, Texas Professional Services Agreement APPENDIX I Mrapilir SCHAUMBURG POLK, 2022 Schedule of Hourly Rates and Expenses ADMINISTRATIVE ASSISTANT $70.00 /HOUR SURVEY CREW $180.00 /HOUR SURVEYOR I $60.00 /HOUR SURVEYOR II $80.00 /HOUR SURVEYOR III $100.00 /HOUR SURVEYOR IV $120.00 /HOUR SURVEYOR TECH $105.00 /HOUR RPLS $170.00 /HOUR CONSTRUCTION REPRESENTATIVE I $80.00 /HOUR CONSTRUCTION REPRESENTATIVE II $110.00 /HOUR CONSTRUCTION REPRESENTATIVE III $130.00 /HOUR DESIGN TECHNICIAN I $60.00 /HOUR DESIGN TECHNICIAN II $85.00 /HOUR DESIGN TECHNICIAN III $110.00 /HOUR DESIGN TECHNICIAN IV $135.00 /HOUR ENGINEER I/II $115.00 /HOUR ENGINEER III $130.00 /HOUR ENGINEER IV $155.00 /HOUR ENGINEER V $185.00 /HOUR ENGINEER VI $205.00 /HOUR ENGINEER VII $230.00 /HOUR ENGINEER VIII $250.00 /HOUR ENGINEER IX $270.00 /HOUR REIMBURSABLE EXPENSES Mileage IRS Allowable Rate Travel and Meals Actual Cost x 1.10 Misc. Reimbursable Expenses Actual Cost x 1.10 OUTSIDE CONSULTANT RATES Associate Engineer Civil, Electrical, Environmental, Mechanical,etc. up to$225.00/HOUR Subconsultants Actual Cost x 1.10 EJCDC E-520 Short Form of Agreement Between Owner and Engineer for Professional Services. Copyright©2009 National Society of Professional Engineers for EJCDC.All rights reserved. APPENDIX 1 Schaumburg & Polk, Inc. furnishes General Liability Insurance, Professional Liability Insurance and State of Texas mandatory limits of Worker's Compensation insurance. Preparation for and furnishing expert witness testimony will be billed at three times the hourly rates shown above for the various classifications. Rates Effective: January 1,2021(adjusted annually) EJCDC E-520 Short Form of Agreement Between Owner and Engineer for Professional Services. Copyright©2009 National Society of Professional Engineers for EJCDC.All rights reserved. Exhibit A—Scope of Services and Budget Dallas and 4th Street Elevated Storage Tank Piping Repairs Page 1 of 4 Scope of Services to be provided are enumerated below: 1. Specifications and Contract Documents: Prepare specifications that describe the work to be performed. Bid documents will be prepared for use in obtaining bids. Contract documents will be EJCDC standard as described in agreement or other Owner provided contract document. The budget for this service is based on a site visit to the tank and discussions with City staff as what the piping repairs need to be included in the project. The proposed repairs will consist of removing and replacing the existing Asbestos Cement (A/C) 12" diameter tank fill line from the City's 12" system line to the tank fill line inside the dry riser, including removing and replacing two 12"gate valves on the system line, removing and replacing a 12"motor operated with a new 12" gate valve, removing and replacing an existing 8" gate valve on the tank drain line, all piping, and fittings. The project also includes the abandonment of the existing the 8" fill line bypass line, inspection and repair of the existing dry riser lighting system and installation of new light fixtures on the ground level of the dry riser. In addition, the project will'include removal of existing wooden shelving at the bottom of the dry riser and placement of a leveling course of crushed limestone of on the ground level of the dry riser. 2. Bid Phase: Assist Owner in advertising for and obtaining bids, conduct pre-bid conference, issue addenda as appropriate to clarify, correct, or change the Bidding Documents. Consult with Owner as to the acceptability of subcontractors, suppliers, and other individuals and entities proposed by Contractor for those portions of the Work as to which such acceptability is required by the Bidding Documents. Attend the Bid opening, prepare Bid tabulation sheets, and assist Owner in evaluating Bids or proposals and in assembling and awarding contracts for the Work. 3. Construction Phase: Engineer will provide the following: 1. General Administration of Construction Contract. Consult with Owner and act as Owner's representative as provided in the General Conditions. All of Owner's instructions to Contractor will be issued through Engineer, who shall have authority to act on behalf of Owner in dealings with Contractor to the extent provided in this Agreement and said General Conditions except as otherwise provided in writing. 2. Pre-Construction Conference. Participate in a pre-construction conference prior to commencement of Work at the Site. 3. Visits to Site and Observation of Construction. In connection with observations of Work in progress. Make visits to the Site at intervals appropriate to the various stages of construction, as Engineer deems necessary, in order to observe as an experienced and qualified design professional the progress and quality of the Work. Such visits and EJCDC E-520 Short Form of Agreement Between Owner and Engineer for Professional Services. Copyright©2009 National Society of Professional Engineers for EJCDC.All rights reserved. Exhibit A—Scope of Services and Budget Dallas and 4th Street Elevated Storage Tank Piping Repairs Page 2 of 4 observations by Engineer, are to be limited to spot checking, selective sampling, and similar methods of general observation of the Work based on Engineer's exercise of professional judgment. Based on information obtained during such visits and such observations, Engineer will determine in general if Contractor's work is proceeding in accordance with the Contract Documents, and Engineer shall keep Owner informed of the progress of the Work. a. The purpose of Engineer's visits will be to enable Engineer to better carry out the duties and responsibilities assigned to and undertaken by Engineer during the Construction Phase and, in addition, by the exercise of Engineer's efforts as an experienced and qualified design professional, to provide for Owner a greater degree of confidence that the completed Work will conform in general to the Contract Documents. Engineer shall not, during such visits or as a result of such observations of Contractor's work in progress, supervise, direct, or have control over the Work, nor shall Engineer have authority over or responsibility for the means, methods, techniques, sequences, or procedures of construction selected by Contractor, for safety precautions and programs incident to the Work, or for any failure of Contractor to comply with Laws and Regulations applicable to Contractor's furnishing and performing the Work. Accordingly, Engineer neither guarantees the performance of any Contractor nor assumes responsibility for any Contractor's failure to furnish and perform its work in accordance with the Contract Documents. 4. Defective Work Have authority to disapprove or reject Contractor's work while it is in progress if, on the basis of such observations, Engineer believes that such work will not produce a completed project that conforms generally to the Contract Documents or that it will prejudice the integrity of the design concept of the completed project as a functioning whole as indicated in the Contract Documents. 5. Clarifications and Interpretations; Field Orders. Issue necessary clarifications and interpretations of the Contract Documents as appropriate to the orderly completion of the Work. Such clarifications and interpretations will be consistent with the intent of and reasonably inferable from the Contract Documents. Engineer may issue Field Orders authorizing minor variations from the requirements of the Contract Documents. 6. Change Orders and Work Change Directives. Recommend Change Orders and Work Change Directives to Owner, as appropriate, and prepare Change Orders and Work Change Directives as required. 7. Shop Drawings and Samples. Review and approve or take other appropriate action in respect to Shop Drawings and Samples and other data which Contractor is required to submit, but only for conformance with the information given in the Contract Documents. EJCDC E-520 Short Form of Agreement Between Owner and Engineer for Professional Services. Copyright©2009 National Society of Professional Engineers for EJCDC.All rights reserved. Exhibit A—Scope of Services and Budget Dallas and 4th Street Elevated Storage Tank Piping Repairs Page 3 of 4 Such reviews and approvals or other action will not extend to means, methods, techniques, sequences or procedures of construction or to safety precautions and programs incident thereto. Engineer has an obligation to meet any Contractors submittal schedule that has earlier been acceptable to Engineer. 8. Substitutes and "or-equal." Evaluate and determine the acceptability of substitute or "or- equal" materials and equipment proposed by Contractor. 9. Inspections and Tests. Require such special inspections or tests of the Work as deemed reasonably necessary, and receive and review all certificates of inspections, tests, and approvals required by Laws and Regulations or the Contract Documents. Engineer's review of such certificates will be for the purpose of determining that the results certified indicate compliance with the Contract Documents and will not constitute an independent evaluation that the content or procedures of such inspections, tests, or approvals comply with the requirements of the Contract Documents. Engineer shall be entitled to rely on the results of such tests. 10. Disagreements between Owner and Contractor. Render formal written decisions on all claims of Owner and Contractor relating to the acceptability of the Work or the interpretation of the requirements of the Contract Documents pertaining to the execution and progress of the Work. In rendering such decisions, Engineer shall be fair and not show partiality to Owner or Contractor and shall not be liable in connection with any decision rendered in good faith in such capacity. 11. Applications for Payment. Based on Engineer's observations as an experienced and qualified design professional and on review of Applications for Payment and accompanying supporting documentation: a. Determine the amounts that Engineer recommends Contractor be paid. Such recommendations of payment will be in writing and will constitute Engineer's representation to Owner, based on such observations and review, that, to the best of Engineer's knowledge, information and belief, the Work has progressed to the point indicated, the quality of such is generally in accordance with the Contract Documents and the conditions precedent to Contractor's being entitled to such payment appear to have been fulfilled in so far as it is Engineer's responsibility to observe the Work. b. By recommending any payment, Engineer shall not thereby be deemed to have represented that observations made by Engineer to check the quality or quantity of the Work as it is performed and furnished have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work beyond the responsibilities specifically assigned to Engineer in this Agreement and the Contract EJCDC E-520 Short Form of Agreement Between Owner and Engineer for Professional Services. Copyright©2009 National Society of Professional Engineers for EJCDC.All rights reserved. Exhibit A—Scope of Services and Budget Dallas and 4th Street Elevated Storage Tank Piping Repairs Page 4 of 4 Documents. Neither Engineer's review of the Work for the purposes of recommending payments nor Engineer's recommendation of any payment including final payment will impose on Engineer responsibility to supervise, direct, or control the Work in progress or for the means, methods, techniques, sequences, or procedures of construction or safety precautions or programs incident thereto, or Contractor's compliance with Laws and Regulations applicable to the Work. 12. Contractor's Completion Documents. Receive and review maintenance and operating instructions,schedules, and guarantees. Engineer shall transmit these documents to Owner. 13. Substantial Completion. Promptly after notice from Contractor that Contractor considers the entire Work ready for its intended use, in company with Owner and Contractor, conduct an inspection to determine if the Work is Substantially Complete. If after considering any objections of Owner, Engineer considers the Work Substantially Complete, Engineer shall deliver a certificate of Substantial Completion to Owner and Contractor. 14. Final Notice of Acceptability of the Work Conduct a final payment inspection to determine if the completed Work of Contractor is acceptable so that Engineer may recommend, in writing, final payment to Contractor. Accompanying the recommendation for final payment, Engineer shall also provide a notice that the Work is acceptable to the best of Engineer's knowledge, information, and belief and based on the extent of the services provided by Engineer under this Agreement. 4. Additional Services: If additional services are identified during the undertaking of the above services (e.g. additional effort for rigging and time to allow for more detailed inspection, development of details for work beyond that described in the Section 2. Specifications and Contract Documents, additional site visits or extension of construction time in excess of 90 days), engineer will provide the additional services based on an agreed scope of services and cost as approved by Owner prior to undertaking the services. Additional services will not be invoiced without Owner's prior approval. Payment for services will be based on the following: Specifications and Contract Documents $19,700 Bid Phase $6,600 Construction Phase $15,900 Total Fee $-12,200 E.ICDC E-520 Short Form of Agreement Between Owner and Engineer for Professional Services. Copyright©2009 National Society of Professional Engineers for EJCDC.All rights reserved.