Loading...
HomeMy WebLinkAboutPR 24863: AUTHORIZING THE CITY MANAGER TO ENTER INTO A PROFESSIONAL SERVICES AGREEMENT WITH PBK ARCHITECTS INC. vgiltq rrp ur T www.PortArthurTx.gov INTEROFFICE MEMORANDUM Date: March 27, 2026 To: The Honorable Mayor and City Council Through: Ronald Burton, CPM, City Manager From: George Davis, Director of Pleasure Island RE: P.R. No. 24863 —A Resolution Authorizing the City Manager or His Designee to Enter into a Contract with PBK Architects Inc, of Houston,Texas, for Design Services Related to the Nature/Visitor Center on Pleasure Island. Introduction: The City Council is being asked to approve P.R.No.24863, authorizing the City Manager or his designee to enter into a contract with PBK Architects Inc,of Houston,Texas,for Design Services Related to the Nature/Visitor Center on Pleasure Island. Background: Per resolution 26-024,the City Council authorized the City Manager to negotiate a contract with PBK, of Houston, Texas, for the design of a Nature/Visitor Center on Pleasure Island. PBK Architects Inc has since prepared an evaluation outlining the scope of work and budget for the new construction and proposes to develop a design schedule,hold review meetings, and prepare construction documents for bidding. Budget Impact: Compensation for the services described above shall be based on 8% of the final construction cost, not to exceed $272,000.00, and shall be available from Account Number 450-00-000- 8512-00-00-000, Project Number PI0012.DES. Recommendation: It is recommended that the City Council approve P.R.No. 24863, authorizing the City Manager or his designee to enter into a contract with PBK Architects Inc, of Houston, Texas, for Design Services Related to the Nature/Visitor Center on Pleasure Island. "Remember,we are here to serve the Citizens of Port Arthur" P.O.Box 1089 X Port Arthur,Texas 77641-1089 X 409.983.8182 X FAX 409.983.8294 P. R. 24863 3/27/2026 GD-TNR RESOLUTION NO. A RESOLUTION AUTHORIZING THE CITY MANAGER TO ENTER INTO A PROFESSIONAL SERVICES AGREEMENT WITH PBK ARCHITECTS INC, OF HOUSTON, TEXAS, FOR THE DESIGN SERVICES RELATED TO THE NATURE/VISITOR CENTER ON PLEASURE ISLAND IN THE TOTAL AMOUNT NOT TO EXCEED $272,000.00; FUNDING IS AVAILABLE IN ACCOUNT NUMBER 450-00-000-8512-00-00-000 PROJECT NUMBER. PI0012.DES WHEREAS, the City of Port Arthur has identified the need to renovate and enhance facilities on Pleasure Island, including improvements to the proposed Nature/Visitor Center at Lakefront Park, in order to provide a functional, welcoming, and aesthetically pleasing environment for residents and visitors; and WHEREAS, the proposed Nature/Visitor Center improvements include, but are not limited to, the development of a main lobby, gift shop, meeting space, and restroom facilities, together with associated architectural and interior design elements; and WHEREAS, pursuant to Resolution No. 26-024, the City Council authorized the City Manager to negotiate a professional services agreement with PBK Architects, Inc., of Houston, Texas, for design services associated with the Nature/Visitor Center project; and WHEREAS, PBK Architects Inc has prepared an evaluation to establish the scope of work and estimated budget needed to perform the construction of a Nature/Visitor Center in Lakefront Park on Pleasure Island; and WHEREAS, PBK Architects, Inc. proposes to provide comprehensive design services, including preparation of a design schedule, participation in review meetings, and development of construction drawings and specifications sufficient to facilitate the City's solicitation of competitive bids for construction; and WHEREAS, it is deemed in the best interest to enter into a professional services agreement with PBK Architects Inc to provide design services for the Nature/Visitor Center on Pleasure Island, attached hereto as Exhibit "A". Compensation for the services described above shall be based on 8% of the final construction cost, not to exceed $272,000.00, as delineated in Exhibit "A". NOW, THEREFORE, BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF PORT ARTHUR,TEXAS: Section 1. That the facts and opinions in the preamble are true and correct. Section 2. The City Manager, or his designee, is hereby authorized to execute a professional services agreement, in substantially the same form as attached hereto as Exhibit "A," with PBK Architects, Inc., of Houston, Texas, for architectural and design services related to the Nature/Visitor Center project on Pleasure Island. Compensation for the services described above shall be based on 8% of the final construction cost, not to exceed $272,000.00. Funding for said services is hereby appropriated from Account No. 450-00-000-8512-00- 00-000, Project No. PI0012.DES. Section 3. That a copy of the caption of this Resolution be spread upon the Minutes of the City Council. READ, ADOPTED AND APPROVED THIS day of April, A.D., 2026, at a Regular Meeting of the City Council of the City of Port Arthur,by the following vote: P. R. #24863 3/27/2026 gd AYES:(Mayor) Councilmembers: NOES: Charlotte M. Moses Mayor ATTEST: APPROVED AS TO FORM: 4 :. -'<---).......-- Sherri Bellard Roxann Pais Cotroneo City Secretary City Attorney APPRO i FOR ADMINISTRATION: Oil ' ... CO"' _ Ronald B 7., N George avis, A, CPM City M. - .ger Director of Pleasure Island APP' S 9 D AS TO THE AVAILABILITY OF FUNDS: /. , ,--„, Lii,, . ... e '.rf( yn)Boswel , A, ICMA-CM Clifton . Williams, Jr., Director of Finance Purchasing Manager P. R. # 24863 3/27/2026 gd Exhibit "A" STATE OF TEXAS § CITY OF PORT ARTHUR,TEXAS § AGREEMENT FOR PROFESSIONAL SERVICES COUNTY OF JEFFERSON § This Agreement for Professional Services("Agreement")is made by and between the City of Port Arthur,Texas,a Texas home-rule municipality located in Jefferson County,Texas("City"), and PBK ARCHITECTS INC, OF HOUSTON, TEXAS ("Professional") (individually, each a "Party" and collectively, "Parties"), acting by and through the Parties' authorized representatives. Recitals: WHEREAS, the City desires to engage the services of the Professional as an independent contractor and not as an employee in accordance with the terms and conditions set forth in this Agreement; and WHEREAS, Professional desires to render professional services in accordance with the terms and conditions set forth in this Agreement. NOW, THEREFORE, in exchange for the mutual covenants set forth herein and other valuable consideration, the sufficiency and receipt of which is hereby acknowledged, the Parties agree as follows: Article I Employment of Professional The professional will perform as an independent contractor for all services under this Agreement in accordance with the Statutory Standard of Care, codified in Tex. Civ. Prac. &Rem. Code § 130.0021(b)(1). Article II Term 2.1 The term of this Agreement shall begin on the last date of execution hereof by all parties hereto (the "Effective Date") and shall remain in effect for an estimated one (1) year, including the time necessary to develop the project deliverables, subject to change upon request or mutual agreement(s). 2.2 The Professional may terminate this Agreement by giving thirty (30) days' prior written notice to the City. In the event of such termination by Professional, Professional shall be entitled to compensation for services satisfactorily completed in accordance with this Agreement prior to the date of such termination. 2.3 City may terminate this Agreement by giving ten (10) days prior written notice to Professional. In the event of such termination by City, Professional shall be entitled to compensation for services satisfactorily completed in accordance with this Agreement prior to the date of such termination. Upon receipt of such notice from City, Professional shall immediately terminate working on, placing orders or entering into contracts for supplies, assistance, facilities or materials in connection with this Agreement and shall proceed to promptly cancel all existing contracts insofar as they are related to this Agreement. 2.4 Upon notice of termination by Professional or City, Professional shall immediately surrender all project documents produced by Professional and its subcontractors up to and including the date on which termination notice was given. Article III Scope of Services 3.1 Professional shall perform the services specifically set forth in Exhibit A, attached hereto and incorporated herein by reference, entitled"Scope of Services." In case of conflict with the language of Exhibit A and the provisions of this Agreement, the provisions of this Agreement shall control. Any additional services require the prior approval of the City Council of the City. 3.2 The Parties acknowledge and agree that any and all opinions provided by Professional represent the best judgment of Professional, in accordance with the Standard of Care. Article IV Schedule of Work 4.1 Professional agrees to commence services upon written direction from City and to complete the tasks set forth in Exhibit A, Scope of Services, in accordance with a work schedule established by City(the"Schedule"), which is attached hereto and incorporated as Exhibit A. 4.2 In the event Professional's performance of this Agreement is delayed or interfered with by acts of City or others, Professional may request an extension of time for the performance of same as hereinafter provided, and City shall determine whether to authorize any increase in fee or price, or to authorize damages or additional compensation as a consequence of such delays, within a reasonable time after receipt of Professional's request. 4.3 No allowance of any extension of time, for any cause whatsoever, shall be claimed or made by Professional, unless Professional shall have made written request upon City for such extension not later than thirty (30) business days after the occurrence of the cause serving as the basis for such extension request, and unless City and Professional have agreed in writing upon the allowance of such additional time. Article V Compensation and Method of Payment 5.1 City shall pay Professional for the services specifically as set forth in ExhibitA and in accordance with the Rate Schedule in an amount not to exceed$272,000.00for said services. 5.2 Each month Professional shall submit to City an invoice supporting the amount for which payment is sought. Each invoice shall also state the percentage of work completed on the Page 2 of 11 City of Port Arthur, Texas Professional Services Agreement Project through the end of the then submitted billing period,the total of the current invoice amount, and a running total balance for the Project to date. 5.3 Within thirty (30) days of receipt of each such monthly invoice, City shall make monthly payments in the amount shown by Professional's approved monthly invoice and other documentation submitted. 5.4 Professional shall be solely responsible for the payment of all costs and expenses related to the services provided pursuant to this Agreement including, but not limited to, travel, copying and facsimile charges,reproduction charges, and telephone, internet, e-mail, and postage charges, except as set forth in Exhibit A. 5.5 Nothing contained in this Agreement shall require City to pay for any services that are unsatisfactory as determined by City or which is not performed in compliance with the terms of this Agreement, nor shall failure to withhold payment pursuant to the provisions of this section constitute a waiver of any right, at law or in equity, which City may have if Professional is in default, including the right to bring legal action for damages or for specific performance of this Agreement. Waiver of any default under this Agreement shall not be deemed a waiver of any subsequent default. Article VI Devotion of Time, Personnel, and Equipment 6.1 Professional shall devote such time as reasonably necessary for the satisfactory performance of the services under this Agreement. City reserves the right to revise or expand the scope of services after due approval by City as City may deem necessary, but in such event City shall pay Professional compensation for such services at mutually agreed upon charges or rates, a copy of the Rate Schedule is attached hereto as Exhibit A, and within the time schedule prescribed by City, and without decreasing the effectiveness of the performance of services required under this Agreement. In any event, when Professional is directed to revise or expand the scope of services under this Agreement, Professional shall provide City a written proposal for the entire costs involved in performing such additional services. Prior to Professional undertaking any revised or expanded services as directed by City under this Agreement, City must authorize in writing the nature and scope of the services and accept the method and amount of compensation and the time involved in all phases of the Project. 6.2 It is expressly understood and agreed to by Professional that any compensation not specified in this Agreement may require approval by the City Council of the City of Port Arthur and may be subject to current budget year limitations. 6.3 To the extent reasonably necessary for Professional to perform the services under this Agreement, Professional shall be authorized to engage the services of any agents, assistants, persons, or corporations that Professional may deem proper to aid or assist in the performance of the services under this Agreement. The cost of such personnel and assistance shall be borne exclusively by Professional. Page 3 of 11 City of Port Arthur, Texas Professional Services Agreement tr`r:!•g'.'2' .r.co-�^^iiR.m....F+r..s..:iS.;'4r• yFc,::...,... .m. .. .. ., - 6.4 Professional shall furnish the facilities, equipment,telephones, facsimile machines, email facilities, and personnel necessary to perform the services required under this Agreement unless otherwise provided herein. Article VII Relationship of Parties 7.1 It is understood and agreed by and between the Parties that in satisfying the conditions and requirements of this Agreement, Professional is acting as an independent contractor, and City assumes no responsibility or liability to any third party in connection with the services provided by Professional under this Agreement. All services to be performed by Professional pursuant to this Agreement shall be in the capacity of an independent contractor, and not as an agent, servant, representative, or employee of City. Professional shall supervise the performance of its services and shall be entitled to control the manner, means and methods by which Professional's services are to be performed, subject to the terms of this Agreement. As such, City shall not train Professional, require Professional to complete regular oral or written reports, require Professional to devote his full-time services to City, or dictate Professional's sequence of work or location at which Professional performs Professional's work, except as may be set forth in Exhibit A. Article VIII Insurance 8.1 Before commencing work, Professional shall, at its own expense, procure, pay for and maintain during the term of this Agreement the following insurance written by companies approved by the state of Texas and acceptable to City. Professional shall furnish to the City Manager certificates of insurance executed by the insurer or its authorized agent stating coverages, limits, expiration dates and compliance with all applicable required provisions. Certificates shall reference the project/contract number and be addressed as follows: City of Port Arthur, Texas Attention: Ronald Burton, City Manager 444 4th Street Port Arthur, Texas 77640-1089 A. Commercial General Liability insurance, including, but not limited to Premises/Operations, Personal & Advertising Injury, Products/Completed Operations, Independent Contractors and Contractual Liability, with minimum combined single limits of $500,000 per occurrence, $500,000 Products/Completed Operations Aggregate, and $500,000 general aggregate. Coverage must be written on an occurrence form. The General Aggregate shall apply on a per project basis. B. Workers' Compensation insurance with statutory limits; and Employers' Liability coverage with minimum limits for bodily injury: 1)by accident, $100,000 each accident, and 2) by disease, $100,000 per employee with a per policy aggregate of $500,000. Page 4 of 11 City of Port Arthur, Texas Professional Services Agreement C. Business Automobile Liability insurance covering owned, hired, and non- owned vehicles, with a minimum combined bodily injury and property damage limit of $500,000 per occurrence. D. Professional Liability Insurance to provide coverage against claims which the Professional and all professionals engaged or employed by the Professional become legally obligated to pay as damages arising out of the performance of professional services caused by error, omission, or negligent act, with minimum limits of$1,000,000 per claim, $1,000,000 annual aggregate NOTE:If the insurance is written on a claims-made form, coverage shall be continuous(by renewal or extended reporting period) for not less than thirty-six (36) months following completion of this Agreement and acceptance by City. 8.2 With reference to the foregoing required insurance, Professional shall endorse applicable insurance policies as follows: A. A waiver of subrogation in favor of City, its officials, employees, and officers shall be contained in the Workers' Compensation insurance policy. B. The City, its officials, employees, and officers shall be named as additional insureds on the Commercial General Liability policy, by using endorsement CG2026 or broader. C. All insurance policies shall be endorsed to the effect that the City will receive at least thirty(30)days'notice prior to cancellation,non-renewal, or termination of the policies. 8.3 All insurance shall be purchased from an insurance company that meets a financial rating of B+VI or better as assigned by A.M. Best Company or equivalent. Article IX Right to Inspect Records 9.1 Professional agrees that City shall have access to and the right to examine any directly pertinent books, documents, papers and records of Professional involving transactions relating to this Agreement. Professional agrees that City shall have access during normal working hours to all necessary Professional facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. City shall give Professional reasonable advance notice of intended audits. 9.2 Professional further agrees to include in subcontract(s), if any, a provision that any subcontractor agrees that City shall have access to and the right to examine any directly pertinent Page 5 of 11 City of Port Arthur, Texas Professional Services Agreement books, documents, papers and records of such subcontractor involving transactions related to the subcontract, and further, that City shall have access during normal working hours to all such subcontractor facilities and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this section. City shall give any such subcontractor reasonable advance notice of intended audits. Article X Miscellaneous 10.1 Entire Agreement. This Agreement and any and all Exhibits attached hereto constitutes the sole and only agreement between the Parties and supersedes any prior or contemporaneous understandings,written agreements or oral agreements between the Parties with respect to the subject matter of this Agreement. 10.2 Authorization. Each Party represents that it has full capacity and authority to grant all rights and assume all obligations granted and assumed under this Agreement. 10.3 Assignment. Professional may not assign this Agreement in whole or in part without the prior written consent of City. In the event of an assignment by Professional to which the City has consented, the assignee shall agree in writing with the City to personally assume, perform, and be bound by all the covenants and obligations contained in this Agreement. 10.4 Successors and Assigns. Subject to the provisions regarding assignment, this Agreement shall be binding on and inure to the benefit of the Parties and their respective heirs, executors, administrators, legal representatives, successors and assigns. 10.5 Governing Law and Exclusive Venue. The laws of the State of Texas shall govern this Agreement, and exclusive venue for any legal action concerning this Agreement shall be in a District Court with appropriate jurisdiction in Jefferson County, Texas. The Parties agree to submit to the personal and subject matter jurisdiction of said court. 10.6 Amendments. This Agreement may be amended only by the mutual written agreement of the Parties. 10.7 Severability. In the event any one or more of the provisions contained in this Agreement shall for any reason be held to be invalid, illegal, or unenforceable in any respect by a court of competent jurisdiction, such invalidity, illegality or unenforceability shall not affect any other provision in this Agreement, and this Agreement shall be construed as if such invalid,illegal, or unenforceable provision had never been contained in this Agreement. 10.8 Survival of Covenants and Terms. Any of the representations, warranties, covenants,and obligations of the Parties,as well as any rights and benefits of the Parties,pertaining to a period of time following the termination of this Agreement shall survive termination, including,but not limited to, Section 3.3, Article X, and, in particular, Sections 10.13 and 10.14. 10.9 Recitals. The recitals to this Agreement are incorporated herein. Page 6 of 11 City of Port Arthur, Texas Professional Services Agreement 10.10 Notice. Any notice required or permitted to be delivered hereunder may be sent by first class mail, overnight courier or by confirmed telefax or facsimile to the address specified below, or to such other Party or address as either Party may designate in writing, and shall be deemed received three (3) days after delivery set forth herein: If intended for City: City of Port Arthur,Texas 444 4th Street Port Arthur, Texas 77640 Attn: Ronald Burton, City Manager Copy to: City of Port Arthur, Texas 444 4th Street Port Arthur, Texas 77640 Attn: Roxann Pais Cotroneo, City Attorney 10.11 Counterparts. This Agreement may be executed by the Parties hereto in separate counterparts, each of which when so executed and delivered shall be deemed an original, but all such counterparts shall together constitute one and the same instrument. Each counterpart may consist of any number of copies hereof each signed by less than all, but together signed by all of, the Parties hereto. 10.12 Exhibits. The exhibits attached hereto are incorporated herein and made a part hereof for all purposes. 10.13 Professional's Liability. Acceptance of the Project Documents by City shall not constitute nor be deemed a release of the responsibility and liability of Professional,its employees, associates, agents or subcontractors for the accuracy and competency of their designs, working drawings, specifications or other documents and work; nor shall such acceptance be deemed an assumption of responsibility by City for any defect in the Project Documents or other documents and work prepared by Professional, its employees, associates, agents or sub-consultants. 10.14 Indemnification. PROFESSIONAL AGREES TO INDEMNIFY AND HOLD HARMLESS CITY FROM AND AGAINST ANY AND ALL LIABILITIES, DAMAGES, CLAIMS,SUITS,COSTS (INCLUDING COURT COSTS,REASONABLE ATTORNEY'S FEES AND COSTS OF INVESTIGATION)AND ACTIONS BY REASON OF INJURY TO OR DEATH OF ANY PERSON OR DAMAGE TO OR LOSS OF PROPERTY TO THE EXTENT CAUSED BY PROFESSIONAL'S NEGLIGENT PERFORMANCE OF SERVICES UNDER THIS AGREEMENT OR BY REASON OF ANY ACT OR OMISSION ON THE PART OF PROFESSIONAL, ITS OFFICERS, DIRECTORS, SERVANTS, AGENTS, EMPLOYEES, REPRESENTATIVES, CONTRACTORS, SUBCONTRACTORS, LICENSEES, SUCCESSORS OR PERMITTED ASSIGNS (EXCEPT WHEN SUCH LIABILITY, CLAIMS, SUITS, COSTS, INJURIES, DEATHS OR DAMAGES ARISE FROM OR ARE ATTRIBUTED TO THE NEGLIGENCE OF Page 7 of 11 City of Port Arthur, Texas Professional Services Agreement THE CITY.PROFESSIONAL OBLIGATIONS UNDER THIS SECTION SHALL NOT BE LIMITED TO THE LIMITS OF COVERAGE OF INSURANCE MAINTAINED OR REQUIRED TO BE MAINTAINED BY PROFESSIONAL UNDER THIS AGREEMENT. IF THIS AGREEMENT IS A CONTRACT FOR ENGINEERING OR ARCHITECTURAL SERVICES, THEN THIS SECTION IS LIMITED BY THE INDEMNITY SPECIFIED IN § 271.904 OF THE TEXAS LOCAL GOVERNMENT CODE, AS AMENDED. THIS SECTION SHALL SURVIVE TERMINATION OF THIS AGREEMENT 10.15 Conflicts of Interest. Professional represents that no official or employee of City has any direct or indirect pecuniary interest in this Agreement. Any misrepresentation by Professional under this section shall be grounds for termination of this Agreement and shall be grounds for recovery of any loss, cost, expense or damage incurred by City as a result of such misrepresentation. 10.16 Default. If at any time during the term of this Agreement, Professional shall fail to commence the services in accordance with the provisions of this Agreement or fail to diligently provide services in an efficient, timely and careful manner and in strict accordance with the provisions of this Agreement or fail to use an adequate number or quality of personnel to complete the services or fail to perform any of Professional's obligations under this Agreement, then City shall have the right, if Professional shall not cure any such default after thirty (30) days written notice thereof, to terminate this Agreement. Any such act by City shall not be deemed a waiver of any other right or remedy of City. If after exercising any such remedy due to Professional's nonperformance under this Agreement, the cost to City to complete the services to be performed under this Agreement is in excess of that part of the contract sum which as not theretofore been paid to Professional hereunder, Professional shall be liable for and shall reimburse City for such excess costs. 10.17 Confidential Information. Professional hereby acknowledges and agrees that its representatives may have access to or otherwise receive information during the furtherance of Professional's obligations in accordance with this Agreement, which is of a confidential, non- public or proprietary nature. Professional shall treat any such information received in full confidence and will not disclose or appropriate such Confidential Information for Professional's own use or the use of any third party at any time during or subsequent to this Agreement. As used herein, "Confidential Information"means all oral and written information concerning the City, its affiliates and subsidiaries, and all oral and written information concerning City or its activities, that is of a non-public,proprietary or confidential nature including,without limitation,information pertaining to customer lists, services,methods, processes and operating procedures, together with all analyses,compilations, studies or other documents,whether prepared by Professional or others, which contain or otherwise reflect such information. The term "Confidential Information" shall not include such information that is or becomes generally available to the public other than as a result of disclosure to Professional, or is required to be disclosed by a governmental authority under applicable law. 10.18 Remedies. No right or remedy granted or reserved to the Parties is exclusive of any other right or remedy herein by law or equity provided or permitted; but each right or remedy shall be cumulative of every other right or remedy given hereunder. No covenant or condition of Page 8 of 11 City of Port Arthur, Texas Professional Services Agreement this Agreement maybe waived without written consent of the Parties. Forbearance or indulgence by either Party shall not constitute a waiver of any covenant or condition to be performed pursuant to this Agreement. 10.19 No Third Party Beneficiary. For purposes of this Agreement, including the intended operation and effect of this Agreement, the Parties specifically agree and contract that: (1) this Agreement only affects matters between the Parties to this Agreement, and is in no way intended by the Parties to benefit or otherwise affect any third person or entity notwithstanding the fact that such third person or entity may be in contractual relationship with City or Professional or both;and(2)the terms of this Agreement are not intended to release,either by contract or operation of law, any third person or entity from obligations owing by them to either City or Professional. [The Remainder of this Page Intentionally Left Blankj Page 9 of 11 City of Port Arthur, Texas Professional Services Agreement EXECUTED this day of , 2026. CITY: CITY OF PORT ARTHUR,TEXAS, A Texas home-rule municipality, By: Ronald Burton, City Manager ATTEST: Sherri Bellard, City Secretary APPROVED AS TO FORM: Roxann Pais Cotroneo, City Attorney EXECUTED this day of , 2026. PROFESSIONAL: PBK ARCHITECTS INC, OF HOUSTON, TEXAS By: Name: Page 10 of 11 City of Port Arthur, Texas Professional Services Agreement Exhibit A Scope of Services/ Schedule Page 11 of 11 City of Port Arthur, Texas Professional Services Agreement e . • !t &IIIA o Document BIOI® — 2017 Standard Form of Agreement Between Owner and Architect AGREEMENT made as of the twenty-sixth day of March in the year 2026 (In words, indicate day, month and year.) ADDITIONS AND DELETIONS: BETWEEN the Architect's client identified as the Owner: The author of this document has (Name, legal status, address and other information) added information needed for its completion.The author may also City of Port Arthur have revised the text of the original 520 Pleasure Pier Blvd. AIA standard form.An Additions and Port Arthur,Texas 77640 Deletions Report that notes added information as well as revisions to the standard form text is available from and the Architect: the author and should be reviewed.A (Name, legal status, address and other information) vertical line in the left margin of this document indicates where the author PBK Architects,Inc. has added necessary information 11 Greenway Plaza,22nd Floor and where the author has added to or Houston,Texas 77046 deleted from the original AIA text. This document has important legal consequences.Consultation with an for the following Project: attorney is encouraged with respect (Name, location and detailed description) to its completion or modification. City of Port Arthur Nature Center The Owner and Architect agree as follows. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Init. Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) TABLE OF ARTICLES 1 INITIAL INFORMATION 2 ARCHITECT'S RESPONSIBILITIES 3 SCOPE OF ARCHITECT'S BASIC SERVICES 4 SUPPLEMENTAL AND ADDITIONAL SERVICES 5 OWNER'S RESPONSIBILITIES 6 COST OF THE WORK 7 COPYRIGHTS AND LICENSES 8 CLAIMS AND DISPUTES 9 TERMINATION OR SUSPENSION 10 MISCELLANEOUS PROVISIONS 11 COMPENSATION 12 SPECIAL TERMS AND CONDITIONS 13 SCOPE OF THE AGREEMENT ARTICLE 1 INITIAL INFORMATION § 1.1 This Agreement is based on the Initial Information set forth in this Section 1.1. (For each item in this section, insert the information or a statement such as "not applicable"or "unknown at time of execution.') § 1.1.1 The Owner's program for the Project: (Insert the Owner's program, identify documentation that establishes the Owner's program, or state the manner in which the program will be developed.) § 1.1.2 The Project's physical characteristics: (Identify or describe pertinent information about the Project's physical characteristics, such as size; location; dimensions;geotechnical reports;site boundaries; topographic surveys; traffic and utility studies;availability of public and private utilities and services; legal description of the site, etc.) This project is to be located at Lakefront Park on Pleasure Island in Port Arthur, TX. PBK will work in concert with the City of Port Arthur to provide complete professional services for the design of a 10,000 square foot Nature Center. § 1.1.3 The Owner's budget for the Cost of the Work,as defined in Section 6.1: (Provide total and, if known, a line item breakdown.) To Be Determined § 1.1.4 The Owner's anticipated design and construction milestone dates: .1 Design phase milestone dates, if any: Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 2 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@alacontracts.com. User Notes: (1483422006) To Be Determined .2 Construction commencement date: To Be Determined .3 Substantial Completion date or dates: To Be Determined .4 Other milestone dates: To Be Determined § 1.1.5 The Owner intends the following procurement and delivery method for the Project: (Identify method such as competitive bid or negotiated contract, as well as any requirements for accelerated or fast-track design and construction, multiple bid packages, or phased construction.) Competitive Sealed Proposal delivery method § 1.1.6 The Owner's anticipated Sustainable Objective for the Project: (Identify and describe the Owner's Sustainable Objective for the Project, if any.) N/A § 1.1.6.1 If the Owner identifies a Sustainable Objective,the Owner and Architect shall complete and incorporate AIA Document E204TM_2017,Sustainable Projects Exhibit,into this Agreement to define the terms,conditions and services related to the Owner's Sustainable Objective.If E204-2017 is incorporated into this agreement,the Owner and Architect shall incorporate the completed E204-2017 into the agreements with the consultants and contractors performing services or Work in any way associated with the Sustainable Objective. § 1.1.7 The Owner identifies the following representative in accordance with Section 5.3: (List name, address, and other contact information.) Ronald Burton City Manager City of Port Arthur Pleasure Island 520 Pleasure Pier Blvd. Port Arthur,TX 77640 § 1.1.8 The persons or entities,in addition to the Owner's representative,who are required to review the Architect's submittals to the Owner are as follows: (List name, address, and other contact information.) § 1.1.9 The Owner shall retain the following consultants and contractors: (List name, legal status, address, and other contact information.) .1 Geotechnical Engineer: Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 3 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) .2 Civil Engineer: .3 Other,if any: (List any other consultants and contractors retained by the Owner.) § 1.1.10 The Architect identifies the following representative in accordance with Section 2.3: (List name, address, and other contact information.) Sofia Dusek, Senior Principal PBK Architects,Inc. 11 Greenway Plaza,22nd Floor Houston,Texas 77046 § 1.1.11 The Architect shall retain the consultants identified in Sections 1.1.11.1 and 1.1.11.2: (List name, legal status, address, and other contact information.) § 1.1.11.1 Consultants retained under Basic Services: .1 Structural Engineer: Kubala Engineers 11 Greenway Plaza, 15th Floor Houston,Texas 77046 .2 Mechanical Engineer: LEAF Engineers 11 Greenway Plaza, 15th Floor Houston,Texas 77046 .3 Electrical Engineer: LEAF Engineers 11 Greenway Plaza, 15th Floor Houston,Texas 77046 .4 Civil Engineer: DIG Engineers 11 Greenway Plaza, 15th Floor Houston,Texas 77046 .5 Building Envelope Engineer: Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 4 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) BEAM 11 Greenway Plaza, 15th Floor Houston,Texas 77046 .6 Landscape Architect: Clark Condon Associates Inc 10401 Stella Link Road Houston,Texas 77025 § 1.1.11.2 Consultants retained under Supplemental Services: § 1.1.12 Other Initial Information on which the Agreement is based: § 1.2 The Owner and Architect may rely on the Initial Information. Both parties,however,recognize that the Initial Information may materially change and,in that event,the Owner and the Architect shall appropriately adjust the Architect's services,schedule for the Architect's services,and the Architect's compensation.The Owner shall adjust the Owner's budget for the Cost of the Work and the Owner's anticipated design and construction milestones,as necessary,to accommodate material changes in the Initial Information. § 1.3 The parties shall agree upon written protocols governing the transmission and use of,and reliance on, Instruments of Service or any other information or documentation in digital form. § 1.3.1 Any use of,or reliance on,all or a portion of a building information model without agreement to written protocols governing the use of,and reliance on,the information contained in the model shall be at the using or relying party's sole risk and without liability to the other party and its contractors or consultants,the authors of,or contributors to,the building information model,and each of their agents and employees. ARTICLE 2 ARCHITECT'S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement.The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances.The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner's knowledge and consent,the Architect shall not engage in any activity,or accept any employment,interest or contribution that would reasonably appear to compromise the Architect's professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement.If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains,the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than ($ )for each occurrence and ($ )in the aggregate for bodily injury and property damage. Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 5 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) § 2.5.2 Automobile Liability covering vehicles owned,and non-owned vehicles used,by the Architect with policy limits of not less than ($ )per accident for bodily injury,death of any person,and property damage arising out of the ownership,maintenance and use of those motor vehicles,along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance,provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages required under Sections 2.5.1 and 2.5.2,and in no event shall any excess or umbrella liability insurance provide narrower coverage than the primary policy.The excess policy shall not require the exhaustion of the underlying limits only through the actual payment by the underlying insurers. § 2.5.4 Workers' Compensation at statutory limits. § 2.5.5 Employers'Liability with policy limits not less than ($ )each accident, ($ )each employee,and ($ ) policy limit. § 2.5.6 Professional Liability covering negligent acts,errors and omissions in the performance of professional services with policy limits of not less than ($ )per claim and ($ )in the aggregate. § 2.5.7 Additional Insured Obligations.To the fullest extent permitted by law,the Architect shall cause the primary and excess or umbrella policies for Commercial General Liability and Automobile Liability to include the Owner as an additional insured for claims caused in whole or in part by the Architect's negligent acts or omissions.The additional insured coverage shall be primary and non-contributory to any of the Owner's insurance policies and shall apply to both ongoing and completed operations. § 2.5.8 The Architect shall provide certificates of insurance to the Owner that evidence compliance with the requirements in this Section 2.5. ARTICLE 3 SCOPE OF ARCHITECT'S BASIC SERVICES § 3.1 The Architect's Basic Services consist of those described in this Article 3 and include usual and customary structural,mechanical,and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services. § 3.1.1 The Architect shall manage the Architect's services,research applicable design criteria,attend Project meetings,communicate with members of the Project team,and report progress to the Owner. § 3.1.2 The Architect shall coordinate its services with those services provided by the Owner and the Owner's consultants.The Architect shall be entitled to rely on,and shall not be responsible for,the accuracy,completeness,and timeliness of,services and information furnished by the Owner and the Owner's consultants.The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any error,omission,or inconsistency in such services or information. § 3.1.3 As soon as practicable after the date of this Agreement,the Architect shall submit for the Owner's approval a schedule for the performance of the Architect's services. The schedule initially shall include anticipated dates for the commencement of construction and for Substantial Completion of the Work as set forth in the Initial Information.The schedule shall include allowances for periods of time required for the Owner's review,for the performance of the Owner's consultants,and for approval of submissions by authorities having jurisdiction over the Project.Once approved by the Owner,time limits established by the schedule shall not,except for reasonable cause,be exceeded by the Architect or Owner.With the Owner's approval,the Architect shall adjust the schedule,if necessary,as the Project proceeds until the commencement of construction. § 3.1.4 The Architect shall not be responsible for an Owner's directive or substitution,or for the Owner's acceptance of non-conforming Work,made or given without the Architect's written approval. Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 6 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) § 3.1.5 The Architect shall contact governmental authorities required to approve the Construction Documents and entities providing utility services to the Project.The Architect shall respond to applicable design requirements imposed by those authorities and entities. § 3.1.6 The Architect shall assist the Owner in connection with the Owner's responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project. § 3.2 Schematic Design Phase Services § 3.2.1 The Architect shall review the program and other information furnished by the Owner,and shall review laws, codes,and regulations applicable to the Architect's services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner's program,schedule,budget for the Cost of the Work,Project site,the proposed procurement and delivery method,and other Initial Information,each in terms of the other,to ascertain the requirements of the Project.The Architect shall notify the Owner of(1)any inconsistencies discovered in the information,and(2)other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project.The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner,the Architect shall prepare and present,for the Owner's approval,a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner's approval of the preliminary design,the Architect shall prepare Schematic Design Documents for the Owner's approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan,if appropriate,and preliminary building plans,sections and elevations;and may include some combination of study models,perspective sketches,or digital representations.Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives,such as material choices and building orientation,together with other considerations based on program and aesthetics,in developing a design that is consistent with the Owner's program,schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials,building systems and equipment,together with other considerations based on program and aesthetics,in developing a design for the Project that is consistent with the Owner's program,schedule,and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner,and request the Owner's approval. § 3.3 Design Development Phase Services § 3.3.1 Based on the Owner's approval of the Schematic Design Documents,and on the Owner's authorization of any adjustments in the Project requirements and the budget for the Cost of the Work,the Architect shall prepare Design Development Documents for the Owner's approval.The Design Development Documents shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans,sections,elevations,typical construction details,and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural,structural,mechanical and electrical systems,and other appropriate elements.The Design Development Documents shall also include outline specifications that identify major materials and systems and establish,in general,their quality levels. § 3.3.2 The Architect shall update the estimate of the Cost of the Work prepared in accordance with Section 6.3. Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 7 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) lr § 3.3.3 The Architect shall submit the Design Development Documents to the Owner,advise the Owner of any adjustments to the estimate of the Cost of the Work,and request the Owner's approval. § 3.4 Construction Documents Phase Services § 3.4.1 Based on the Owner's approval of the Design Development Documents,and on the Owner's authorization of any adjustments in the Project requirements and the budget for the Cost of the Work,the Architect shall prepare Construction Documents for the Owner's approval.The Construction Documents shall illustrate and describe the further development of the approved Design Development Documents and shall consist of Drawings and Specifications setting forth in detail the quality levels and performance criteria of materials and systems and other requirements for the construction of the Work.The Owner and Architect acknowledge that,in order to perform the Work,the Contractor will provide additional information,including Shop Drawings,Product Data,Samples and other similar submittals,which the Architect shall review in accordance with Section 3.6.4. § 3.4.2 The Architect shall incorporate the design requirements of governmental authorities having jurisdiction over the Project into the Construction Documents. § 3.4.3 During the development of the Construction Documents,the Architect shall assist the Owner in the development and preparation of(1)procurement information that describes the time,place,and conditions of bidding, including bidding or proposal forms;(2)the form of agreement between the Owner and Contractor;and(3)the Conditions of the Contract for Construction(General,Supplementary and other Conditions).The Architect shall also compile a project manual that includes the Conditions of the Contract for Construction and Specifications,and may include bidding requirements and sample forms. § 3.4.4 The Architect shall update the estimate for the Cost of the Work prepared in accordance with Section 6.3. § 3.4.5 The Architect shall submit the Construction Documents to the Owner,advise the Owner of any adjustments to the estimate of the Cost of the Work,take any action required under Section 6.5,and request the Owner's approval. § 3.5 Procurement Phase Services § 3.5.1 General The Architect shall assist the Owner in establishing a list of prospective contractors.Following the Owner's approval of the Construction Documents,the Architect shall assist the Owner in(1)obtaining either competitive bids or negotiated proposals;(2)confirming responsiveness of bids or proposals;(3)determining the successful bid or proposal,if any;and,(4)awarding and preparing contracts for construction. § 3.5.2 Competitive Bidding § 3.5.2.1 Bidding Documents shall consist of bidding requirements and proposed Contract Documents. § 3.5.2.2 The Architect shall assist the Owner in bidding the Project by: .1 facilitating the distribution of Bidding Documents to prospective bidders; .2 organizing and conducting a pre-bid conference for prospective bidders; .3 preparing responses to questions from prospective bidders and providing clarifications and interpretations of the Bidding Documents to the prospective bidders in the form of addenda;and, .4 organizing and conducting the opening of the bids,and subsequently documenting and distributing the bidding results,as directed by the Owner. § 3.5.2.3 If the Bidding Documents permit substitutions,upon the Owner's written authorization,the Architect shall, as an Additional Service,consider requests for substitutions and prepare and distribute addenda identifying approved substitutions to all prospective bidders. § 3.5.3 Negotiated Proposals § 3.5.3.1 Proposal Documents shall consist of proposal requirements and proposed Contract Documents. § 3.5.3.2 The Architect shall assist the Owner in obtaining proposals by: .1 facilitating the distribution of Proposal Documents for distribution to prospective contractors and requesting their return upon completion of the negotiation process; .2 organizing and participating in selection interviews with prospective contractors; Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 8 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) .3 preparing responses to questions from prospective contractors and providing clarifications and interpretations of the Proposal Documents to the prospective contractors in the form of addenda;and, .4 participating in negotiations with prospective contractors,and subsequently preparing a summary report of the negotiation results,as directed by the Owner. § 3.5.3.3 If the Proposal Documents permit substitutions,upon the Owner's written authorization,the Architect shall, as an Additional Service,consider requests for substitutions and prepare and distribute addenda identifying approved substitutions to all prospective contractors. § 3.6 Construction Phase Services § 3.6.1 General § 3.6.1.1 The Architect shall provide administration of the Contract between the Owner and the Contractor as set forth below and in AIA Document A201TM-2017,General Conditions of the Contract for Construction.If the Owner and Contractor modify AIA Document A201-2017,those modifications shall not affect the Architect's services under this Agreement unless the Owner and the Architect amend this Agreement. § 3.6.1.2 The Architect shall advise and consult with the Owner during the Construction Phase Services.The Architect shall have authority to act on behalf of the Owner only to the extent provided in this Agreement.The Architect shall not have control over,charge of,or responsibility for the construction means,methods,techniques,sequences or procedures,or for safety precautions and programs in connection with the Work,nor shall the Architect be responsible for the Contractor's failure to perform the Work in accordance with the requirements of the Contract Documents.The Architect shall be responsible for the Architect's negligent acts or omissions,but shall not have control over or charge of,and shall not be responsible for,acts or omissions of the Contractor or of any other persons or entities performing portions of the Work. § 3.6.1.3 Subject to Section 4.2 and except as provided in Section 3.6.6.5,the Architect's responsibility to provide Construction Phase Services commences with the award of the Contract for Construction and terminates on the date the Architect issues the final Certificate for Payment. § 3.6.2 Evaluations of the Work § 3.6.2.1 The Architect shall visit the site at intervals appropriate to the stage of construction,or as otherwise required in Section 4.2.3,to become generally familiar with the progress and quality of the portion of the Work completed,and to determine,in general,if the Work observed is being performed in a manner indicating that the Work,when fully completed,will be in accordance with the Contract Documents.However,the Architect shall not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work.On the basis of the site visits, the Architect shall keep the Owner reasonably informed about the progress and quality of the portion of the Work completed,and promptly report to the Owner(1)known deviations from the Contract Documents,(2)known deviations from the most recent construction schedule submitted by the Contractor,and(3)defects and deficiencies observed in the Work. § 3.6.2.2 The Architect has the authority to reject Work that does not conform to the Contract Documents.Whenever the Architect considers it necessary or advisable,the Architect shall have the authority to require inspection or testing of the Work in accordance with the provisions of the Contract Documents,whether or not the Work is fabricated, installed or completed.However,neither this authority of the Architect nor a decision made in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect to the Contractor, Subcontractors,suppliers,their agents or employees,or other persons or entities performing portions of the Work. § 3.6.2.3 The Architect shall interpret and decide matters concerning performance under,and requirements of,the Contract Documents on written request of either the Owner or Contractor. The Architect's response to such requests shall be made in writing within any time limits agreed upon or otherwise with reasonable promptness. § 3.6.2.4 Interpretations and decisions of the Architect shall be consistent with the intent of,and reasonably inferable from,the Contract Documents and shall be in writing or in the form of drawings.When making such interpretations and decisions,the Architect shall endeavor to secure faithful performance by both Owner and Contractor,shall not show partiality to either,and shall not be liable for results of interpretations or decisions rendered in good faith.The Architect's decisions on matters relating to aesthetic effect shall be final if consistent with the intent expressed in the Contract Documents. In it. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 9 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) § 3.6.2.5 Unless the Owner and Contractor designate another person to serve as an Initial Decision Maker,as that term is defined in AIA Document A201-2017,the Architect shall render initial decisions on Claims between the Owner and Contractor as provided in the Contract Documents. § 3.6.3 Certificates for Payment to Contractor § 3.6.3.1 The Architect shall review and certify the amounts due the Contractor and shall issue certificates in such amounts.The Architect's certification for payment shall constitute a representation to the Owner,based on the Architect's evaluation of the Work as provided in Section 3.6.2 and on the data comprising the Contractor's Application for Payment,that,to the best of the Architect's knowledge,information and belief,the Work has progressed to the point indicated,the quality of the Work is in accordance with the Contract Documents,and that the Contractor is entitled to payment in the amount certified.The foregoing representations are subject to(1)an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion,(2)results of subsequent tests and inspections,(3)correction of minor deviations from the Contract Documents prior to completion,and(4) specific qualifications expressed by the Architect. § 3.6.3.2 The issuance of a Certificate for Payment shall not be a representation that the Architect has(1)made exhaustive or continuous on-site inspections to check the quality or quantity of the Work,(2)reviewed construction means,methods,techniques,sequences or procedures,(3)reviewed copies of requisitions received from Subcontractors and suppliers and other data requested by the Owner to substantiate the Contractor's right to payment, or(4)ascertained how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. § 3.6.3.3 The Architect shall maintain a record of the Applications and Certificates for Payment. § 3.6.4 Submittals § 3.6.4.1 The Architect shall review the Contractor's submittal schedule and shall not unreasonably delay or withhold approval of the schedule.The Architect's action in reviewing submittals shall be taken in accordance with the approved submittal schedule or,in the absence of an approved submittal schedule,with reasonable promptness while allowing sufficient time,in the Architect's professional judgment,to permit adequate review. § 3.6.4.2 The Architect shall review and approve,or take other appropriate action upon,the Contractor's submittals such as Shop Drawings,Product Data and Samples,but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. Review of such submittals is not for the purpose of determining the accuracy and completeness of other information such as dimensions,quantities,and installation or performance of equipment or systems,which are the Contractor's responsibility.The Architect's review shall not constitute approval of safety precautions or construction means,methods,techniques,sequences or procedures.The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component. § 3.6.4.3 If the Contract Documents specifically require the Contractor to provide professional design services or certifications by a design professional related to systems,materials,or equipment,the Architect shall specify the appropriate performance and design criteria that such services must satisfy.The Architect shall review and take appropriate action on Shop Drawings and other submittals related to the Work designed or certified by the Contractor's design professional,provided the submittals bear such professional's seal and signature when submitted to the Architect.The Architect's review shall be for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect shall be entitled to rely upon,and shall not be responsible for,the adequacy and accuracy of the services,certifications,and approvals performed or provided by such design professionals. § 3.6.4.4 Subject to Section 4.2,the Architect shall review and respond to requests for information about the Contract Documents.The Architect shall set forth,in the Contract Documents,the requirements for requests for information. Requests for information shall include,at a minimum,a detailed written statement that indicates the specific Drawings or Specifications in need of clarification and the nature of the clarification requested.The Architect's response to such requests shall be made in writing within any time limits agreed upon,or otherwise with reasonable promptness.If appropriate,the Architect shall prepare and issue supplemental Drawings and Specifications in response to the requests for information. Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 10 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) § 3.6.4.5 The Architect shall maintain a record of submittals and copies of submittals supplied by the Contractor in accordance with the requirements of the Contract Documents. § 3.6.5 Changes in the Work § 3.6.5.1 The Architect may order minor changes in the Work that are consistent with the intent of the Contract Documents and do not involve an adjustment in the Contract Sum or an extension of the Contract Time. Subject to Section 4.2,the Architect shall prepare Change Orders and Construction Change Directives for the Owner's approval and execution in accordance with the Contract Documents. § 3.6.5.2 The Architect shall maintain records relative to changes in the Work. § 3.6.6 Project Completion § 3.6.6.1 The Architect shall: .1 conduct inspections to determine the date or dates of Substantial Completion and the date of final completion; .2 issue Certificates of Substantial Completion; .3 forward to the Owner,for the Owner's review and records,written warranties and related documents required by the Contract Documents and received from the Contractor;and, .4 issue a final Certificate for Payment based upon a final inspection indicating that,to the best of the Architect's knowledge,information,and belief,the Work complies with the requirements of the Contract Documents. § 3.6.6.2 The Architect's inspections shall be conducted with the Owner to check conformance of the Work with the requirements of the Contract Documents and to verify the accuracy and completeness of the list submitted by the Contractor of Work to be completed or corrected. § 3.6.6.3 When Substantial Completion has been achieved,the Architect shall inform the Owner about the balance of the Contract Sum remaining to be paid the Contractor,including the amount to be retained from the Contract Sum,if any,for final completion or correction of the Work. § 3.6.6.4 The Architect shall fonvard to the Owner the following information received from the Contractor: (1) consent of surety or sureties,if any,to reduction in or partial release of retainage or the making of final payment;(2) affidavits,receipts,releases and waivers of liens,or bonds indemnifying the Owner against liens;and(3)any other documentation required of the Contractor under the Contract Documents. § 3.6.6.5 Upon request of the Owner,and prior to the expiration of one year from the date of Substantial Completion, the Architect shall,without additional compensation,conduct a meeting with the Owner to review the facility operations and performance. ARTICLE 4 SUPPLEMENTAL AND ADDITIONAL SERVICES § 4.1 Supplemental Services § 4.1.1 The services listed below are not included in Basic Services but may be required for the Project.The Architect shall provide the listed Supplemental Services only if specifically designated in the table below as the Architect's responsibility,and the Owner shall compensate the Architect as provided in Section 11.2.Unless otherwise specifically addressed in this Agreement,if neither the Owner nor the Architect is designated,the parties agree that the listed Supplemental Service is not being provided for the Project. (Designate the Architect's Supplemental Services and the Owner's Supplemental Services required for the Project by indicating whether the Architect or Owner shall be responsible for providing the identified Supplemental Service. Insert a description of the Supplemental Services in Section 4.1.2 below or attach the description of services as an exhibit to this Agreement.) Supplemental Services Responsibility (Architect, Owner, or not provided) § 4.1.1.1 Programming § 4.1.1.2 Multiple preliminary designs Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 11 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents'Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) Supplemental Services Responsibility (Architect, Owner, or not provided) § 4.1.1.3 Measured drawings § 4.1.1.4 Existing facilities surveys § 4.1.1.5 Site evaluation and planning § 4.1.1.6 Building Information Model management responsibilities § 4.1.1.7 Development of Building Information Models for post construction use § 4.1.1.8 Civil engineering § 4.1.1.9 Landscape design § 4.1.1.10 Architectural interior design § 4.1.1.11 Value analysis § 4.1.1.12 Detailed cost estimating beyond that required in Section 6.3 § 4.1.1.13 On-site project representation § 4.1.1.14 Conformed documents for construction § 4.1.1.15 As-designed record drawings § 4.1.1.16 As-constructed record drawings § 4.1.1.17 Post-occupancy evaluation § 4.1.1.18 Facility support services § 4.1.1.19 Tenant-related services § 4.1.1.20 Architect's coordination of the Owner's consultants § 4.1.1.21 Telecommunications/data design § 4.1.1.22 Security evaluation and planning § 4.1.1.23 Commissioning § 4.1.1.24 Sustainable Project Services pursuant to Section 4.1.3 § 4.1.1.25 Fast-track design services § 4.1.1.26 Multiple bid packages § 4.1.1.27 Historic preservation § 4.1.1.28 Furniture,furnishings,and equipment design § 4.1.1.29 Other services provided by specialty Consultants § 4.1.1.30 Other Supplemental Services § 4.1.2 Description of Supplemental Services § 4.1.2.1 A description of each Supplemental Service identified in Section 4.1.1 as the Architect's responsibility is provided below. (Describe in detail the Architect's Supplemental Services identified in Section 4.1.1 or, if set forth in an exhibit, identify the exhibit. The AIA publishes a number of Standard Form of Architect's Services documents that can be included as an exhibit to describe the Architect's Supplemental Services.) § 4.1.2.2 A description of each Supplemental Service identified in Section 4.1.1 as the Owner's responsibility is provided below. (Describe in detail the Owner's Supplemental Services identified in Section 4.1.1 or, if set forth in an exhibit, identify the exhibit.) Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 12 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) § 4.1.3 If the Owner identified a Sustainable Objective in Article 1,the Architect shall provide,as a Supplemental Service,the Sustainability Services required in AIA Document E204TM-2017,Sustainable Projects Exhibit,attached to this Agreement.The Owner shall compensate the Architect as provided in Section 11.2. § 4.2 Architect's Additional Services The Architect may provide Additional Services after execution of this Agreement without invalidating the Agreement. Except for services required due to the fault of the Architect,any Additional Services provided in accordance with this Section 4.2 shall entitle the Architect to compensation pursuant to Section 11.3 and an appropriate adjustment in the Architect's schedule. § 4.2.1 Upon recognizing the need to perform the following Additional Services,the Architect shall notify the Owner with reasonable promptness and explain the facts and circumstances giving rise to the need.The Architect shall not proceed to provide the following Additional Services until the Architect receives the Owner's written authorization: .1 Services necessitated by a change in the Initial Information,previous instructions or approvals given by the Owner,or a material change in the Project including size,quality,complexity,the Owner's schedule or budget for Cost of the Work,or procurement or delivery method; .2 Services necessitated by the enactment or revision of codes,laws,or regulations,including changing or editing previously prepared Instruments of Service; .3 Changing or editing previously prepared Instruments of Service necessitated by official interpretations of applicable codes,laws or regulations that are either(a)contrary to specific interpretations by the applicable authorities having jurisdiction made prior to the issuance of the building permit,or(b) contrary to requirements of the Instruments of Service when those Instruments of Service were prepared in accordance with the applicable standard of care; .4 Services necessitated by decisions of the Owner not rendered in a timely manner or any other failure of performance on the part of the Owner or the Owner's consultants or contractors; .5 Preparing digital models or other design documentation for transmission to the Owner's consultants and contractors,or to other Owner-authorized recipients; .6 Preparation of design and documentation for alternate bid or proposal requests proposed by the Owner; .7 Preparation for,and attendance at,a public presentation,meeting or hearing; .8 Preparation for,and attendance at,a dispute resolution proceeding or legal proceeding,except where the Architect is party thereto; .9 Evaluation of the qualifications of entities providing bids or proposals; .10 Consultation concerning replacement of Work resulting from fire or other cause during construction; or, .11 Assistance to the Initial Decision Maker,if other than the Architect. § 4.2.2 To avoid delay in the Construction Phase,the Architect shall provide the following Additional Services,notify the Owner with reasonable promptness,and explain the facts and circumstances giving rise to the need. If,upon receipt of the Architect's notice,the Owner determines that all or parts of the services are not required,the Owner shall give prompt written notice to the Architect of the Owner's determination.The Owner shall compensate the Architect for the services provided prior to the Architect's receipt of the Owner's notice. .1 Reviewing a Contractor's submittal out of sequence from the submittal schedule approved by the Architect; .2 Responding to the Contractor's requests for information that are not prepared in accordance with the Contract Documents or where such information is available to the Contractor from a careful study and comparison of the Contract Documents,field conditions,other Owner-provided information, Contractor-prepared coordination drawings,or prior Project correspondence or documentation; .3 Preparing Change Orders and Construction Change Directives that require evaluation of Contractor's proposals and supporting data,or the preparation or revision of Instruments of Service; .4 Evaluating an extensive number of Claims as the Initial Decision Maker;or, .5 Evaluating substitutions proposed by the Owner or Contractor and making subsequent revisions to Instruments of Service resulting therefrom. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Init. Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 13 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) § 4.2.3 The Architect shall provide Construction Phase Services exceeding the limits set forth below as Additional Services.When the limits below are reached,the Architect shall notify the Owner: .1 ( )reviews of each Shop Drawing,Product Data item,sample and similar submittals of the Contractor .2 ( )visits to the site by the Architect during construction .3 ( )inspections for any portion of the Work to determine whether such portion of the Work is substantially complete in accordance with the requirements of the Contract Documents .4 ( )inspections for any portion of the Work to determine final completion. § 4.2.4 Except for services required under Section 3.6.6.5 and those services that do not exceed the limits set forth in Section 4.2.3,Construction Phase Services provided more than 60 days after(1)the date of Substantial Completion of the Work or(2)the initial date of Substantial Completion identified in the agreement between the Owner and Contractor,whichever is earlier,shall be compensated as Additional Services to the extent the Architect incurs additional cost in providing those Construction Phase Services. § 4.2.5 If the services covered by this Agreement have not been completed within ( )months of the date of this Agreement,through no fault of the Architect,extension of the Architect's services beyond that time shall be compensated as Additional Services. ARTICLE 5 OWNER'S RESPONSIBILITIES § 5.1 Unless otherwise provided for under this Agreement,the Owner shall provide information in a timely manner regarding requirements for and limitations on the Project,including a written program,which shall set forth the Owner's objectives;schedule;constraints and criteria,including space requirements and relationships;flexibility; expandability;special equipment;systems;and site requirements. § 5.2 The Owner shall establish the Owner's budget for the Project,including(1)the budget for the Cost of the Work as defined in Section 6.1;(2)the Owner's other costs;and,(3)reasonable contingencies related to all of these costs. The Owner shall update the Owner's budget for the Project as necessary throughout the duration of the Project until final completion. If the Owner significantly increases or decreases the Owner's budget for the Cost of the Work,the Owner shall notify the Architect.The Owner and the Architect shall thereafter agree to a corresponding change in the Project's scope and quality. § 5.3 The Owner shall identify a representative authorized to act on the Owner's behalf with respect to the Project.The Owner shall render decisions and approve the Architect's submittals in a timely manner in order to avoid unreasonable delay in the orderly and sequential progress of the Architect's services. § 5.4 The Owner shall furnish surveys to describe physical characteristics,legal limitations and utility locations for the site of the Project,and a written legal description of the site.The surveys and legal information shall include,as applicable,grades and lines of streets,alleys,pavements and adjoining property and structures;designated wetlands; adjacent drainage;rights-of-way,restrictions,easements,encroachments,zoning,deed restrictions,boundaries and contours of the site;locations,dimensions,and other necessary data with respect to existing buildings,other improvements and trees;and information concerning available utility services and lines,both public and private, above and below grade,including inverts and depths.All the information on the survey shall be referenced to a Project benchmark. § 5.5 The Owner shall furnish services of geotechnical engineers,which may include test borings,test pits, determinations of soil bearing values,percolation tests,evaluations of hazardous materials,seismic evaluation,ground corrosion tests and resistivity tests,including necessary operations for anticipating subsoil conditions,with written reports and appropriate recommendations. § 5.6 The Owner shall provide the Supplemental Services designated as the Owner's responsibility in Section 4.1.1. § 5.7 If the Owner identified a Sustainable Objective in Article 1,the Owner shall fulfill its responsibilities as required in AIA Document E204TM_2017,Sustainable Projects Exhibit,attached to this Agreement. § 5.8 The Owner shall coordinate the services of its own consultants with those services provided by the Architect. Upon the Architect's request,the Owner shall furnish copies of the scope of services in the contracts between the AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Init. Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 14 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) Owner and the Owner's consultants.The Owner shall furnish the services of consultants other than those designated as the responsibility of the Architect in this Agreement,or authorize the Architect to furnish them as an Additional Service,when the Architect requests such services and demonstrates that they are reasonably required by the scope of the Project.The Owner shall require that its consultants and contractors maintain insurance,including professional liability insurance,as appropriate to the services or work provided. § 5.9 The Owner shall furnish tests,inspections and reports required by law or the Contract Documents,such as structural,mechanical,and chemical tests,tests for air and water pollution,and tests for hazardous materials. § 5.10 The Owner shall furnish all legal,insurance and accounting services,including auditing services,that may be reasonably necessary at any time for the Project to meet the Owner's needs and interests. § 5.11 The Owner shall provide prompt written notice to the Architect if the Owner becomes aware of any fault or defect in the Project,including errors,omissions or inconsistencies in the Architect's Instruments of Service. § 5.12 The Owner shall include the Architect in all communications with the Contractor that relate to or affect the Architect's services or professional responsibilities.The Owner shall promptly notify the Architect of the substance of any direct communications between the Owner and the Contractor otherwise relating to the Project. Communications by and with the Architect's consultants shall be through the Architect. § 5.13 Before executing the Contract for Construction,the Owner shall coordinate the Architect's duties and responsibilities set forth in the Contract for Construction with the Architect's services set forth in this Agreement.The Owner shall provide the Architect a copy of the executed agreement between the Owner and Contractor,including the General Conditions of the Contract for Construction. § 5.14 The Owner shall provide the Architect access to the Project site prior to commencement of the Work and shall obligate the Contractor to provide the Architect access to the Work wherever it is in preparation or progress. § 5.15 Within 15 days after receipt of a written request from the Architect,the Owner shall furnish the requested information as necessary and relevant for the Architect to evaluate,give notice of,or enforce lien rights. ARTICLE 6 COST OF THE WORK § 6.1 For purposes of this Agreement,the Cost of the Work shall be the total cost to the Owner to construct all elements of the Project designed or specified by the Architect and shall include contractors' general conditions costs, overhead and profit.The Cost of the Work also includes the reasonable value of labor,materials,and equipment, donated to,or otherwise furnished by,the Owner.The Cost of the Work does not include the compensation of the Architect;the costs of the land,rights-of-way,financing,or contingencies for changes in the Work;or other costs that are the responsibility of the Owner. § 6.2 The Owner's budget for the Cost of the Work is provided in Initial Information,and shall be adjusted throughout the Project as required under Sections 5.2,6.4 and 6.5.Evaluations of the Owner's budget for the Cost of the Work, and the preliminary estimate of the Cost of the Work and updated estimates of the Cost of the Work,prepared by the Architect,represent the Architect's judgment as a design professional. It is recognized,however,that neither the Architect nor the Owner has control over the cost of labor,materials,or equipment;the Contractor's methods of determining bid prices;or competitive bidding,market,or negotiating conditions.Accordingly,the Architect cannot and does not warrant or represent that bids or negotiated prices will not vary from the Owner's budget for the Cost of the Work,or from any estimate of the Cost of the Work,or evaluation,prepared or agreed to by the Architect. § 6.3 In preparing estimates of the Cost of Work,the Architect shall be permitted to include contingencies for design, bidding,and price escalation;to determine what materials,equipment,component systems,and types of construction are to be included in the Contract Documents;to recommend reasonable adjustments in the program and scope of the Project;and to include design alternates as may be necessary to adjust the estimated Cost of the Work to meet the Owner's budget. The Architect's estimate of the Cost of the Work shall be based on current area,volume or similar conceptual estimating techniques.If the Owner requires a detailed estimate of the Cost of the Work,the Architect shall provide such an estimate,if identified as the Architect's responsibility in Section 4.1.1,as a Supplemental Service. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of In it. Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 15 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) § 6.4 If,through no fault of the Architect,the Procurement Phase has not commenced within 90 days after the Architect submits the Construction Documents to the Owner,the Owner's budget for the Cost of the Work shall be adjusted to reflect changes in the general level of prices in the applicable construction market. § 6.5 If at any time the Architect's estimate of the Cost of the Work exceeds the Owner's budget for the Cost of the Work,the Architect shall make appropriate recommendations to the Owner to adjust the Project's size,quality,or budget for the Cost of the Work,and the Owner shall cooperate with the Architect in making such adjustments. § 6.6 If the Owner's budget for the Cost of the Work at the conclusion of the Construction Documents Phase Services is exceeded by the lowest bona fide bid or negotiated proposal,the Owner shall .1 give written approval of an increase in the budget for the Cost of the Work; .2 authorize rebidding or renegotiating of the Project within a reasonable time; .3 terminate in accordance with Section 9.5; .4 in consultation with the Architect,revise the Project program,scope,or quality as required to reduce the Cost of the Work;or, .5 implement any other mutually acceptable alternative. § 6.7 If the Owner chooses to proceed under Section 6.6.4,the Architect shall modify the Construction Documents as necessary to comply with the Owner's budget for the Cost of the Work at the conclusion of the Construction Documents Phase Services,or the budget as adjusted under Section 6.6.1.if the Owner requires the Architect to modify the Construction Documents because the lowest bona fide bid or negotiated proposal exceeds the Owner's budget for the Cost of the Work due to market conditions the Architect could not reasonably anticipate,the Owner shall compensate the Architect for the modifications as an Additional Service pursuant to Section 11.3;otherwise the Architect's services for modifying the Construction Documents shall be without additional compensation. In any event,the Architect's modification of the Construction Documents shall be the limit of the Architect's responsibility under this Article 6. ARTICLE 7 COPYRIGHTS AND LICENSES § 7.1 The Architect and the Owner warrant that in transmitting Instruments of Service,or any other information,the transmitting party is the copyright owner of such information or has permission from the copyright owner to transmit such information for its use on the Project. § 7.2 The Architect and the Architect's consultants shall be deemed the authors and owners of their respective Instruments of Service,including the Drawings and Specifications,and shall retain all common law,statutory and other reserved rights,including copyrights. Submission or distribution of Instruments of Service to meet official regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in derogation of the reserved rights of the Architect and the Architect's consultants. § 7.3 The Architect grants to the Owner a nonexclusive license to use the Architect's Instruments of Service solely and exclusively for purposes of constructing,using,maintaining,altering and adding to the Project,provided that the Owner substantially performs its obligations under this Agreement,including prompt payment of all sums due pursuant to Article 9 and Article 11.The Architect shall obtain similar nonexclusive licenses from the Architect's consultants consistent with this Agreement.The license granted under this section permits the Owner to authorize the Contractor,Subcontractors, Sub-subcontractors,and suppliers,as well as the Owner's consultants and separate contractors,to reproduce applicable portions of the Instruments of Service,subject to any protocols established pursuant to Section 1.3,solely and exclusively for use in performing services or construction for the Project.If the Architect rightfully terminates this Agreement for cause as provided in Section 9.4,the license granted in this Section 7.3 shall terminate. § 7.3.1 In the event the Owner uses the Instruments of Service without retaining the authors of the Instruments of Service,the Owner releases the Architect and Architect's consultant(s)from all claims and causes of action arising from such uses.The Owner,to the extent permitted by law,further agrees to indemnify and hold harmless the Architect and its consultants from all costs and expenses,including the cost of defense,related to claims and causes of action asserted by any third person or entity to the extent such costs and expenses arise from the Owner's use of the Instruments of Service under this Section 7.3.1.The terms of this Section 7.3.1 shall not apply if the Owner rightfully terminates this Agreement for cause under Section 9.4. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Init. Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 16 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) § 7.4 Except for the licenses granted in this Article 7,no other license or right shall be deemed granted or implied under this Agreement.The Owner shall not assign,delegate,sublicense,pledge or otherwise transfer any license granted herein to another party without the prior written agreement of the Architect.Any unauthorized use of the Instruments of Service shall be at the Owner's sole risk and without liability to the Architect and the Architect's consultants. § 7.5 Except as otherwise stated in Section 7.3,the provisions of this Article 7 shall survive the termination of this Agreement. ARTICLE 8 CLAIMS AND DISPUTES § 8.1 General § 8.1.1 The Owner and Architect shall commence all claims and causes of action against the other and arising out of or related to this Agreement,whether in contract,tort,or otherwise, in accordance with the requirements of the binding dispute resolution method selected in this Agreement and within the period specified by applicable law,but in any case not more than 10 years after the date of Substantial Completion of the Work.The Owner and Architect waive all claims and causes of action not commenced in accordance with this Section 8.1.1. § 8.1.2 To the extent damages are covered by property insurance,the Owner and Architect waive all rights against each other and against the contractors,consultants,agents,and employees of the other for damages,except such rights as they may have to the proceeds of such insurance as set forth in AIA Document A201-2017,General Conditions of the Contract for Construction.The Owner or the Architect,as appropriate,shall require of the contractors,consultants, agents,and employees of any of them,similar waivers in favor of the other parties enumerated herein. § 8.1.3 The Architect and Owner waive consequential damages for claims,disputes,or other matters in question, arising out of or relating to this Agreement.This mutual waiver is applicable,without limitation,to all consequential damages due to either party's termination of this Agreement,except as specifically provided in Section 9.7. § 8.2 Mediation § 8.2.1 Any claim,dispute or other matter in question arising out of or related to this Agreement shall be subject to mediation as a condition precedent to binding dispute resolution.if such matter relates to or is the subject of a lien arising out of the Architect's services,the Architect may proceed in accordance with applicable law to comply with the lien notice or filing deadlines prior to resolution of the matter by mediation or by binding dispute resolution. § 8.2.2 The Owner and Architect shall endeavor to resolve claims,disputes and other matters in question between them by mediation,which,unless the parties mutually agree otherwise,shall be administered by the American Arbitration Association in accordance with its Construction Industry Mediation Procedures in effect on the date of this Agreement.A request for mediation shall be made in writing,delivered to the other party to this Agreement,and filed with the person or entity administering the mediation. The request may be made concurrently with the filing of a complaint or other appropriate demand for binding dispute resolution but,in such event,mediation shall proceed in advance of binding dispute resolution proceedings,which shall be stayed pending mediation for a period of 60 days from the date of filing,unless stayed for a longer period by agreement of the parties or court order.If an arbitration proceeding is stayed pursuant to this section,the parties may nonetheless proceed to the selection of the arbitrator(s) and agree upon a schedule for later proceedings. § 8.2.3 The parties shall share the mediator's fee and any filing fees equally.The mediation shall be held in the place where the Project is located,unless another location is mutually agreed upon.Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof. § 8.2.4 If the parties do not resolve a dispute through mediation pursuant to this Section 8.2,the method of binding dispute resolution shall be the following: (Check the appropriate box.) [ ] Arbitration pursuant to Section 8.3 of this Agreement [X ] Litigation in a court of competent jurisdiction [ ] Other: (Specify) AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Init. Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 17 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) If the Owner and Architect do not select a method of binding dispute resolution,or do not subsequently agree in writing to a binding dispute resolution method other than litigation,the dispute will be resolved in a court of competent jurisdiction. § 8.3 Arbitration § 8.3.1 If the parties have selected arbitration as the method for binding dispute resolution in this Agreement,any claim,dispute or other matter in question arising out of or related to this Agreement subject to,but not resolved by, mediation shall be subject to arbitration,which,unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Arbitration Rules in effect on the date of this Agreement.A demand for arbitration shall be made in writing,delivered to the other party to this Agreement,and filed with the person or entity administering the arbitration. § 8.3.1.1 A demand for arbitration shall be made no earlier than concurrently with the filing of a request for mediation, but in no event shall it be made after the date when the institution of legal or equitable proceedings based on the claim, dispute or other matter in question would be barred by the applicable statute of limitations.For statute of limitations purposes,receipt of a written demand for arbitration by the person or entity administering the arbitration shall constitute the institution of legal or equitable proceedings based on the claim,dispute or other matter in question. § 8.3.2 The foregoing agreement to arbitrate,and other agreements to arbitrate with an additional person or entity duly consented to by parties to this Agreement,shall be specifically enforceable in accordance with applicable law in any court having jurisdiction thereof. § 8.3.3 The award rendered by the arbitrator(s)shall be final,and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. § 8.3.4 Consolidation or Joinder § 8.3.4.1 Either party,at its sole discretion,may consolidate an arbitration conducted under this Agreement with any other arbitration to which it is a party provided that(1)the arbitration agreement governing the other arbitration permits consolidation;(2)the arbitrations to be consolidated substantially involve common questions of law or fact; and(3)the arbitrations employ materially similar procedural rules and methods for selecting arbitrator(s). § 8.3.4.2 Either party,at its sole discretion,may include by joinder persons or entities substantially involved in a common question of law or fact whose presence is required if complete relief is to be accorded in arbitration,provided that the party sought to be joined consents in writing to such joinder. Consent to arbitration involving an additional person or entity shall not constitute consent to arbitration of any claim,dispute or other matter in question not described in the written consent. § 8.3.4.3 The Owner and Architect grant to any person or entity made a party to an arbitration conducted under this Section 8.3,whether by joinder or consolidation,the same rights of joinder and consolidation as the Owner and Architect under this Agreement. § 8.4 The provisions of this Article 8 shall survive the termination of this Agreement. ARTICLE 9 TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement,such failure shall be considered substantial nonperformance and cause for termination or,at the Architect's option,cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services,the Architect shall give seven days'written notice to the Owner before suspending services. In the event of a suspension of services,the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services.Before resuming services,the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect's services.The Architect's fees for the remaining services and the time schedules shall be equitably adjusted. In it. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 18 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) § 9.2 If the Owner suspends the Project,the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed,the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect's services.The Architect's fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect,the Architect may terminate this Agreement by giving not less than seven days'written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days' written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days' written notice to the Architect for the Owner's convenience and without cause. § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5,or the Architect terminates this Agreement pursuant to Section 9.3,the Owner shall compensate the Architect for services performed prior to termination,Reimbursable Expenses incurred,and costs attributable to termination,including the costs attributable to the Architect's termination of consultant agreements. § 9.7 In addition to any amounts paid under Section 9.6,if the Owner terminates this Agreement for its convenience pursuant to Section 9.5,or the Architect terminates this Agreement pursuant to Section 9.3,the Owner shall pay to the Architect the following fees: (Set forth below the amount of any termination or licensing fee, or the method for determining any termination or licensing fee.) .1 Termination Fee: .2 Licensing Fee if the Owner intends to continue using the Architect's Instruments of Service: § 9.8 Except as otherwise expressly provided herein,this Agreement shall terminate one year from the date of Substantial Completion. § 9.9 The Owner's rights to use the Architect's Instruments of Service in the event of a termination of this Agreement are set forth in Article 7 and Section 9.7. ARTICLE 10 MISCELLANEOUS PROVISIONS § 10.1 This Agreement shall be governed by the law of the place where the Project is located,excluding that jurisdiction's choice of law rules.If the parties have selected arbitration as the method of binding dispute resolution,the Federal Arbitration Act shall govern Section 8.3. § 10.2 Terms in this Agreement shall have the same meaning as those in AIA Document A201-2017,General Conditions of the Contract for Construction. § 10.3 The Owner and Architect,respectively,bind themselves,their agents,successors,assigns,and legal representatives to this Agreement.Neither the Owner nor the Architect shall assign this Agreement without the written consent of the other,except that the Owner may assign this Agreement to a lender providing financing for the Project if the lender agrees to assume the Owner's rights and obligations under this Agreement,including any payments due to the Architect by the Owner prior to the assignment. § 10.4 If the Owner requests the Architect to execute certificates,the proposed language of such certificates shall be submitted to the Architect for review at least 14 days prior to the requested dates of execution.If the Owner requests the Architect to execute consents reasonably required to facilitate assignment to a lender,the Architect shall execute Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 19 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) all such consents that are consistent with this Agreement,provided the proposed consent is submitted to the Architect for review at least 14 days prior to execution.The Architect shall not be required to execute certificates or consents that would require knowledge,services,or responsibilities beyond the scope of this Agreement. § 10.5 Nothing contained in this Agreement shall create a contractual relationship with,or a cause of action in favor of,a third party against either the Owner or Architect. § 10.6 Unless otherwise required in this Agreement,the Architect shall have no responsibility for the discovery, presence,handling,removal or disposal of,or exposure of persons to,hazardous materials or toxic substances in any form at the Project site. § 10.7 The Architect shall have the right to include photographic or artistic representations of the design of the Project among the Architect's promotional and professional materials.The Architect shall be given reasonable access to the completed Project to make such representations.However,the Architect's materials shall not include the Owner's confidential or proprietary information if the Owner has previously advised the Architect in writing of the specific information considered by the Owner to be confidential or proprietary.The Owner shall provide professional credit for the Architect in the Owner's promotional materials for the Project.This Section 10.7 shall survive the termination of this Agreement unless the Owner terminates this Agreement for cause pursuant to Section 9.4. § 10.8 If the Architect or Owner receives information specifically designated as"confidential"or"business proprietary,"the receiving party shall keep such information strictly confidential and shall not disclose it to any other person except as set forth in Section 10.8.1.This Section 10.8 shall survive the termination of this Agreement. § 10.8.1 The receiving party may disclose"confidential" or"business proprietary"information after 7 days' notice to the other party,when required by law,arbitrator's order,or court order,including a subpoena or other form of compulsory legal process issued by a court or governmental entity,or to the extent such information is reasonably necessary for the receiving party to defend itself in any dispute.The receiving party may also disclose such information to its employees,consultants,or contractors in order to perform services or work solely and exclusively for the Project,provided those employees,consultants and contractors are subject to the restrictions on the disclosure and use of such information as set forth in this Section 10.8. § 10.9 The invalidity of any provision of the Agreement shall not invalidate the Agreement or its remaining provisions.If it is determined that any provision of the Agreement violates any law,or is otherwise invalid or unenforceable,then that provision shall be revised to the extent necessary to make that provision legal and enforceable.In such case the Agreement shall be construed,to the fullest extent permitted by law,to give effect to the parties' intentions and purposes in executing the Agreement. ARTICLE 11 COMPENSATION § 11.1 For the Architect's Basic Services described under Article 3,the Owner shall compensate the Architect as follows: .1 Stipulated Sum (Insert amount) .2 Percentage Basis (Insert percentage value) Eight (8 )%of the Owner's budget for the Cost of the Work,as calculated in accordance with Section 11.6. .3 Other (Describe the method of compensation) In it. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 20 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) § 11.2 For the Architect's Supplemental Services designated in Section 4.1.1 and for any Sustainability Services required pursuant to Section 4.1.3,the Owner shall compensate the Architect as follows: (Insert amount of or basis for, compensation.If necessary, list specific services to which particular methods of compensation apply.) § 11.3 For Additional Services that may arise during the course of the Project, including those under Section 4.2,the Owner shall compensate the Architect as follows: (Insert amount of or basis for, compensation.) § 11.4 Compensation for Supplemental and Additional Services of the Architect's consultants when not included in Section 11.2 or 11.3,shall be the amount invoiced to the Architect plus percent( %),or as follows: (Insert amount of or basis for computing,Architect's consultants'compensation for Supplemental or Additional Services.) § 11.5 When compensation for Basic Services is based on a stipulated sum or a percentage basis,the proportion of compensation for each phase of services shall be as follows: Schematic Design Phase fifteen percent ( 15 %) Design Development Phase twenty percent ( 20 %) Construction Documents thirty-five percent ( 35 %) Phase Procurement Phase five percent ( 5 %) Construction Phase twenty-five percent ( 25 %) Total Basic Compensation one hundred percent ( 100 %) § 11.6 When compensation identified in Section 11.1 is on a percentage basis,progress payments for each phase of Basic Services shall be calculated by multiplying the percentages identified in this Article by the Owner's most recent budget for the Cost of the Work.Compensation paid in previous progress payments shall not be adjusted based on subsequent updates to the Owner's budget for the Cost of the Work. § 11.6.1 When compensation is on a percentage basis and any portions of the Project are deleted or otherwise not constructed,compensation for those portions of the Project shall be payable to the extent services are performed on those portions.The Architect shall be entitled to compensation in accordance with this Agreement for all services performed whether or not the Construction Phase is commenced. § 11.7 The hourly billing rates for services of the Architect and the Architect's consultants are set forth below.The rates shall be adjusted in accordance with the Architect's and Architect's consultants' normal review practices. (If applicable, attach an exhibit of hourly billing rates or insert them below.) Employee or Category Rate($0.00) § 11.8 Compensation for Reimbursable Expenses § 11.8.1 Reimbursable Expenses are in addition to compensation for Basic,Supplemental,and Additional Services and include expenses incurred by the Architect and the Architect's consultants directly related to the Project,as follows: .1 Transportation and authorized out-of-town travel and subsistence; Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 21 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) .2 Long distance services,dedicated data and communication services,teleconferences,Project web sites, and extranets; .3 Permitting and other fees required by authorities having jurisdiction over the Project; .4 Printing,reproductions,plots,and standard form documents; .5 Postage,handling,and delivery; .6 Expense of overtime work requiring higher than regular rates,if authorized in advance by the Owner; .7 Renderings,physical models,mock-ups,professional photography,and presentation materials requested by the Owner or required for the Project; .8 If required by the Owner,and with the Owner's prior written approval,the Architect's consultants' expenses of professional liability insurance dedicated exclusively to this Project,or the expense of additional insurance coverage or limits in excess of that normally maintained by the Architect's consultants; .9 All taxes levied on professional services and on reimbursable expenses; .10 Site office expenses; .11 Registration fees and any other fees charged by the Certifying Authority or by other entities as necessary to achieve the Sustainable Objective;and, .12 Other similar Project-related expenditures. § 11.8.2 For Reimbursable Expenses the compensation shall be the expenses incurred by the Architect and the Architect's consultants plus percent( %)of the expenses incurred. § 11.9 Architect's Insurance.If the types and limits of coverage required in Section 2.5 are in addition to the types and limits the Architect normally maintains,the Owner shall pay the Architect for the additional costs incurred by the Architect for the additional coverages as set forth below: (Insert the additional coverages the Architect is required to obtain in order to satisfy the requirements set forth in Section 2.5, and for which the Owner shall reimburse the Architect.) § 11.10 Payments to the Architect § 11.10.1 Initial Payments § 11.10.1.1 An initial payment of ($ )shall be made upon execution of this Agreement and is the minimum payment under this Agreement.It shall be credited to the Owner's account in the final invoice. § 11.10.1.2 If a Sustainability Certification is part of the Sustainable Objective,an initial payment to the Architect of ($ )shall be made upon execution of this Agreement for registration fees and other fees payable to the Certifying Authority and necessary to achieve the Sustainability Certification. The Architect's payments to the Certifying Authority shall be credited to the Owner's account at the time the expense is incurred. § 11.10.2 Progress Payments § 11.10.2.1 Unless otherwise agreed,payments for services shall be made monthly in proportion to services performed.Payments are due and payable upon presentation of the Architect's invoice. Amounts unpaid ( )days after the invoice date shall bear interest at the rate entered below,or in the absence thereof at the legal rate prevailing from time to time at the principal place of business of the Architect. (Insert rate of monthly or annual interest agreed upon.) § 11.10.2.2 The Owner shall not withhold amounts from the Architect's compensation to impose a penalty or liquidated damages on the Architect,or to offset sums requested by or paid to contractors for the cost of changes in the Work,unless the Architect agrees or has been found liable for the amounts in a binding dispute resolution proceeding. § 11.10.2.3 Records of Reimbursable Expenses,expenses pertaining to Supplemental and Additional Services,and services performed on the basis of hourly rates shall be available to the Owner at mutually convenient times. ARTICLE 12 SPECIAL TERMS AND CONDITIONS Special terms and conditions that modify this Agreement are as follows: Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 22 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) (Include other terms and conditions applicable to this Agreement.) ARTICLE 13 SCOPE OF THE AGREEMENT § 13.1 This Agreement represents the entire and integrated agreement between the Owner and the Architect and supersedes all prior negotiations,representations or agreements,either written or oral. This Agreement may be amended only by written instrument signed by both the Owner and Architect. § 13.2 This Agreement is comprised of the following documents identified below: .1 AIA Document B101T"_2017,Standard Form Agreement Between Owner and Architect .2 Building Information Modeling Exhibit, if completed: .3 Exhibits: (Check the appropriate box for any exhibits incorporated into this Agreement.) [ i AIA Document E204T"_2017, Sustainable Projects Exhibit,dated as indicated below: (Insert the date of the E204-2017 incorporated into this agreement.) [ i Other Exhibits incorporated into this Agreement: (Clearly identify any other exhibits incorporated into this Agreement, including any exhibits and scopes of services identified as exhibits in Section 4.1.2.) .4 Other documents: (List other documents, if any,.forming part of the Agreement.) This Agreement entered into as of the day and year first written abo S ( D OWNER(Signature) ARCHITECT(Signature) 1 Sofia Dusek Senior Principal (Printed name and title) (Printed name, title, and license number, if required) Init. AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 23 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in t accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) Additions and Deletions Report for AIA Document B 101®— 2017 This Additions and Deletions Report,as defined on page 1 of the associated document,reproduces below all text the author has added to the standard form AIA document in order to complete it,as well as any text the author may have added to or deleted from the original AIA text.Added text is shown underlined.Deleted text is indicated with a horizontal line through the original AIA text. Note: This Additions and Deletions Report is provided for information purposes only and is not incorporated into or constitute any part of the associated AIA document.This Additions and Deletions Report and its associated document were generated simultaneously by 1 AIA software at 11:43:03 ET on 03/26/2026. PAGE 1 AGREEMENT made as of the twenty-sixth day of March in the year 2026 City of Port Arthur 520 Pleasure Pier Blvd. Port Arthur,Texas 77640 PBK Architects,Inc. 11 Greenway Plaza,22nd Floor Houston,Texas 77046 City of Port Arthur Nature Center PAGE 2 This project is to be located at Lakefront Park on Pleasure Island in Port Arthur,TX.PBK will work in concert with the City of Port Arthur to provide complete professional services for the design of a 10,000 square foot Nature Center. To Be Determined PAGE 3 To Be Determined To Be Determined To Be Determined To Be Determined Additions and Deletions Report for AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) Competitive Sealed Proposal delivery method N/A Ronald Burton City Manager City of Port Arthur Pleasure Island 520 Pleasure Pier Blvd. Port Arthur,TX 77640 PAGE 4 Sofia Dusek,Senior Principal PBK Architects,Inc. 11 Greenway Plaza,22nd Floor Houston,Texas 77046 Kubala Engineers 11 Greenway Plaza, 15th Floor Houston,Texas 77046 .2 Mechanical Engineer: LEAF Engineers 11 Greenway Plaza, 15th Floor Houston,Texas 77046 .3 Electrical Engineer: LEAF Engineers 11 Greenway Plaza, 15th Floor Houston,Texas 77046 .4 Civil Engineer: .3 Electrical DIG Engineers 11 Greenway Plaza, 15th Floor Houston,Texas 77046 .5 Building Envelope Engineer: BEAM 11 Greenway Plaza, 15th Floor Houston,Texas 77046 Additions and Deletions Report for AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This 2 document was produced at 11:43:03 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) .6 Landscape Architect: Clark Condon Associates Inc 10401 Stella Link Road Houston,Texas 77025 PAGE 17 [X 1 Litigation in a court of competent jurisdiction PAGE 20 Eight (8 J%of the Owner's budget for the Cost of the Work,as calculated in accordance with Section 11.6. PAGE 21 Schematic Design Phase fifteen percent ( 15 %) Design Development Phase twenty percent ( 20 %) Construction Documents thirty-five percent ( 35 %) Phase Procurement Phase five percent ( 5 %) Construction Phase twenty-five percent ( 25 %) PAGE 23 Sofia Dusek Senior Principal Additions and Deletions Report for AIA Document B101—2017.Copyright©1974,1978,1987,1997,2007 and 2017.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This 3 document was produced at 11:43:03 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents°Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) Certification of Document's Authenticity A/A® Document D401 TM — 2003 I,gregory prince,hereby certify,to the best of my knowledge,information and belief,that I created the attached final document simultaneously with its associated Additions and Deletions Report and this certification at 11:43:03 ET on 03/26/2026 under Order No. 3104239853 from AIA Contract Documents software and that in preparing the attached final document I made no changes to the original text of AIA4 Document B 101 TM—2017,Standard Form of Agreement Between Owner and Architect,other than those additions and deletions shown in the associated Additions and Deletions Report. (Signed) (Title) (Dated) AIA Document D401—2003.Copyright©1992 and 2003.All rights reserved."The American Institute of Architects,""American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are trademarks of The American Institute of Architects.This document was produced at 11:43:03 ET on 03/26/2026 under Order No.3104239853 which expires on 12/31/2026,is not for resale,is licensed for one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail docinfo@aiacontracts.com. User Notes: (1483422006) 11 Greenway Plaza, 22nd Floor Houston, Texas 77046 Toll-free: 1-800-938-7272 Fax: 713-961-4571 PBK.com March 11, 2026 VIA: E-MAIL Ronald Burton City Manager City of Port Arthur Pleasure Island, 520 Pleasure Pier Blvd., Port Arthur, TX 77640 Re: City of Port Arthur Nature Center Dear Mr. Burton, Thank you for allowing PBK the opportunity to submit this proposal to provide architectural and engineering services for the proposed City of Port Arthur Nature Center. The following is our understanding of the scope of work for this project. BASIC SCOPE OF WORK This project is to be located at Lakefront Park on Pleasure Island in Port Arthur, TX. PBK will work in concert with the City of Port Arthur to provide complete professional services for the design of a 10,000 square foot Nature Center. Complete professional services shall including the following: - Architectural - Civil - Structural - Mechanical - Electrical - Plumbing The following is a description of the phases of design and construction that PBK will provide: Design:Working with the City of Port Arthur, PBK will provide planning and design services for the project. Numerous options will be explored and modified, until the preferred design is achieved. PBK will provide the necessary documentation, which will effectively portray the design, for presentations to key administrators, end-users and the City Council. Construction Documentation: Once the design phase is approved, the construction documents will begin. These documents will be composed of necessary plans, details, and specifications, which will allow interested general contractors to bid on the project. Proposal& Permitting Phase: It is PBK's understanding that is the preference of the City of Port Arthur to use the Competitive Sealed Proposal delivery method for the selection of a qualified General Contractor. During the proposal phase, PBK will assist the City of Port Arthur Administrators in the process of receiving bid proposals from interested general contractors. Included will be answering questions, issuing addenda, aiding in advertisement, receiving bid proposals, and developing the contract between the Owner and the Contractor. PBK will also ARCHITECTURE \\ ENGINEERING \\ PLANNING \\ TECHNOLOGY \\ FACILITY CONSULTING City of Port Arthur Pleasure Island Nature Center submit all necessary documents to all authorities having jurisdiction and coordinate the management of the permitting process. Construction Administration:The project will be administered in accordance with the construction documents and construction activities of the contractor. Field visits will be documented, and Observations Reports will be executed throughout the construction period by PBK field representatives. Additionally, PBK representatives will attend construction progress meetings, execute meeting minutes and communicate regularly with the contractor on behalf of the City of Port Arthur to maximize quality assurance and quality control. Nearing completion of the work, PBK will initiate a punch list and establish the date of substantial completion. Project Close-Out: Project close-out documents prepared by the contractor will be reviewed, including Operation and Maintenance Manuals (warranties, maintenance contracts, operating instructions, etc.), certificate of inspection and bonds, documentation required with application of final payment, record drawings, etc. Warranty: PBK will coordinate any items reported with the general contractor and will verify that the repair work has been accomplished. COMPENSATION Compensation for the services described above shall be based on 8% of the final construction cost. Included in the fee will be all consultant services listed above. REIMBURSABLE EXPENSES Reimbursables will be limited to any owner-approved costs, as well as any printing and/or reproduction costs, bid ad costs, TAS review, and permitting fees associated with the project documentation. All reimbursable expenses will be billed at cost, with no markup. SCHEDULE A schedule for the scope described above will be determined at a later date. We appreciate the opportunity to provide this proposal and look forward to working with you. Should you have any questions, please do not hesitate to contact me. Sincerely, cS-D•L&/ .0 March 9, 2026 Sofia Dusek, PBK Architects Date Senior Principal ARCHITECTURE \\ ENGINEERING \\ PLANNING \\ TECHNOLOGY \\ FACILITY CONSULTING City of Port Arthur Pleasure Island Nature Center Approved by: Ronald Burton, City of Port Arthur Date City Manager ARCHITECTURE \\ ENGINEERING \\ PLANNING \\ TECHNOLOGY \\ FACILITY CONSULTING